{"bekendtgoerelseNoegle":{"noticeId":{"value":"9fa66f12-f544-4538-96a1-2f946483068f"},"noticeVersion":{"value":"01"},"noticePublicationNumber":{"value":"00832208-2025"}},"htmlDA":"\n\n \n 1 Køber1.1 KøberOfficielt navn: A/S Storebælt\n Køberens retlige status: Offentligretligt organ\n Den ordregivende myndigheds aktivitet: Boliger og offentlige faciliteter\n Den ordregivende enheds aktiviteter: Jernbanetjenester\n \n \n 2 Procedure2.1 ProcedureTitel: Purchase of jet fans for the tunnel at the Great Belt Link\n Beskrivelse: BACKGROUND:
The 160 jet fans in the railway tunnel on the Great Belt Link is at\n the end-of-life cycle and is required to be replaced. The main purposes of the jet\n fans are to remove smoke during a fire and ventilate for safe working environment.
The\n tunnel is approximately 8 km long and at its deepest point the tunnel is 75 meters\n below sea level.
The tunnel consists of two separate tunnels called the south\n and north tunnel with one railway track in each tunnel. The two tunnels are connected\n by 31 cross tunnels, which partly function as an escape route between the two tunnels\n and partly contain installations, such as switch-boards and transformers.
THE\n SCOPE OF THE TENDER
The scope of this tender is to provide project management,\n design, manufacturing, factory testing (FAT), delivery to site, supervision at site\n and documentation for the new jet fans.
Currently there are 80 jet fans installed\n in each tube, totally 160 jet fans. The new jet fans shall be installed at the same\n location as the existing to minimize the works for power supply and fixtures to the\n concrete. The existing brackets, which is fixed to the concrete wall in the tunnel\n shall be reused for mounting the new jet fans.
The new jet fans will have\n higher capacity than the existing jet fans, but the quantity of jet fans will remain\n the same 80 jet fans per tunnel, totally 160 new jet fans.
The jet fans shall\n be delivered with connected power and control cables connected to minimize the works\n at site.
The installation of the jet fans is done during limited closures\n of the railway tunnel. The installation of the jet fans is not part of the scope of\n this tender. It is part of this tender to provide supervision of the installation\n and testing of all jet fans 24 hours a day during the railway tunnel closures. The\n primary scope of the supervision is to approve the installation and testing done by\n a third party contactor and the secondary scope is to assist if there are issues with\n the supplied jet fans and related equipment supplied in this tender.
The\n installation and testing at site of the jet fans are planned into two main phases.
•\n Phase 1 – July 2026 – Test installation of one jet fan in the tunnel.
• Phase\n 2 – May and June 2027 – Installation and testing of the rest of the jet fans.
Further\n information and details are described in tender material.\n Identifikator for proceduren: 9e4cadb5-6491-4c9b-a436-bab7c710432c\n Tidligere bekendtgørelse: 1d0299d4-b87c-48c6-b225-778e7f17183f-01\n \n Udbudsprocedure: Begrænset\n Proceduren er en hasteprocedure: nej\n 2.1.1 FormålKontraktens hovedformål: Varer\n Primær klassifikation (cpv): 42522000 Ventilatorer, ikke til privat brug\n \n 2.1.2 UdførelsesstedPostadresse: Halsskovvej 150 \n \n \n Landsdel (NUTS): Vest- og Sydsjælland (DK022)\n \n Yderligere oplysninger: The place of delivery of the jet fans is the above address. The supervision will take\n place during the installation, which is in the tunnels at the Great Belt Link.\n \n 2.1.3 VærdiAnslået værdi eksklusiv moms: 38.000.000 Dansk krone\n \n 2.1.4 Generelle oplysningerYderligere oplysninger: A/S Storebælt only received non-compliant tenders. Thus, the Contracting Entity chose\n to proceed with a negotiated procedure in accordance with article 50(1)(a) in directive\n 2014/25/EU on procurement by entities operating in the water, energy, transport and\n postal services sectors and repealing Directive 2004/17/EC. The contracting entity\n invited all tenderers to a negotation.
The value stated for the tender is\n stated as the evaluation technical price.\n \n \n Directive 2014/25/EU - The Utilities Directive (Directive 2014/25/EU) is implemented in Danish law by Ministerial\n Order on procurement by entities operating in the water, energy, transport and postal\n services sectors (Ministerial Order No. 1078 of 29 June 2022), which also contains\n supplementary provisions.\n \n \n \n 5 Delkontrakt5.1 Teknisk ID for delkontrakten: LOT-0000Titel: Purchase of jet fans for the tunnel at the Great Belt Link\n Beskrivelse: BACKGROUND:
The 160 jet fans in the railway tunnel on the Great Belt Link is at\n the end-of-life cycle and is required to be replaced. The main purposes of the jet\n fans are to remove smoke during a fire and ventilate for safe working environment.
The\n tunnel is approximately 8 km long and at its deepest point the tunnel is 75 meters\n below sea level.
The tunnel consists of two separate tunnels called the south\n and north tunnel with one railway track in each tunnel. The two tunnels are connected\n by 31 cross tunnels, which partly function as an escape route between the two tunnels\n and partly contain installations, such as switch-boards and transformers.
THE\n SCOPE OF THE TENDER
The scope of this tender is to provide project management,\n design, manufacturing, factory testing (FAT), delivery to site, supervision at site\n and documentation for the new jet fans.
Currently there are 80 jet fans installed\n in each tube, totally 160 jet fans. The new jet fans shall be installed at the same\n location as the existing to minimize the works for power supply and fixtures to the\n concrete. The existing brackets, which is fixed to the concrete wall in the tunnel\n shall be reused for mounting the new jet fans.
The new jet fans will have\n higher capacity than the existing jet fans, but the quantity of jet fans will remain\n the same 80 jet fans per tunnel, totally 160 new jet fans.
The jet fans shall\n be delivered with connected power and control cables connected to minimize the works\n at site.
The installation of the jet fans is done during limited closures\n of the railway tunnel. The installation of the jet fans is not part of the scope of\n this tender. It is part of this tender to provide supervision of the installation\n and testing of all jet fans 24 hours a day during the railway tunnel closures. The\n primary scope of the supervision is to approve the installation and testing done by\n a third party contactor and the secondary scope is to assist if there are issues with\n the supplied jet fans and related equipment supplied in this tender.
The\n installation and testing at site of the jet fans are planned into two main phases.
•\n Phase 1 – July 2026 – Test installation of one jet fan in the tunnel.
• Phase\n 2 – May and June 2027 – Installation and testing of the rest of the jet fans.
Further\n information and details are described in tender material.\n \n 5.1.1 FormålKontraktens hovedformål: Varer\n Primær klassifikation (cpv): 42522000 Ventilatorer, ikke til privat brug\n \n 5.1.2 UdførelsesstedPostadresse: Halsskovvej 150 \n \n \n Landsdel (NUTS): Vest- og Sydsjælland (DK022)\n \n Yderligere oplysninger: The place of delivery of the jet fans is the above address. The supervision will take\n place during the installation, which is in the tunnels at the Great Belt Link.\n \n \n 5.1.4 FornyelseHøjeste antal fornyelser: 0\n \n 5.1.5 VærdiAnslået værdi eksklusiv moms: 38.000.000 Dansk krone\n \n 5.1.6 Generelle oplysningerIndkøbsprojekt, der ikke finansieres med EU-midler\n Udbuddet er omfattet af aftalen om offentlige udbud (GPA): ja\n Yderligere oplysninger: A/S Storebælt only received non-compliant tenders. Thus, the Contracting Entity chose\n to proceed with a negotiated procedure in accordance with article 50(1)(a) in directive\n 2014/25/EU on procurement by entities operating in the water, energy, transport and\n postal services sectors and repealing Directive 2004/17/EC. The contracting entity\n invited all tenderers to a negotation.
The value stated for the tender is\n stated as the evaluation technical price.\n \n 5.1.10 TildelingskriterierKriterium:\n \n Beskrivelse: See Tender Specifications section 5.\n Kategori for tildelingskriteriet tærskel: Vægtning (procentdel, præcis)Tildelingskriterium talværdi: 70\n \n \n Kriterium:\n \n Beskrivelse: See Tender Specifications section 5.\n Kategori for tildelingskriteriet tærskel: Vægtning (procentdel, præcis)Tildelingskriterium talværdi: 15\n \n \n Kriterium:\n Navn: Climate Change Mitigation Plan\n Beskrivelse: See Tender Specifications section 5.\n Kategori for tildelingskriteriet tærskel: Vægtning (procentdel, præcis)Tildelingskriterium talværdi: 15\n \n \n \n 5.1.15 Teknikker\n Oplysninger om det dynamiske indkøbssystem:Intet dynamisk indkøbssystem\n \n \n 5.1.16 Yderligere oplysninger, mægling og gennemgangOrganisation med ansvar for klager: Klagenævnet for Udbud\n Oplysninger om klagefrister: Pursuant to the Danish Act on the Complaints Board for Public Procurement, etc. (lov\n om Klagenævnet for Udbud m.v.) (the Act is available (in Danish) at www.retsinformation.dk),\n the following deadlines apply to the lodging of complaints:
Complaints of\n not having been selected must be submitted to the Danish Complaints Board for Public\n Procurement before the expiry of 20 calendar days, see section 7(1) of the Act, from\n the day after submission of notification to the candidates concerned of the identity\n of the successful tenderer where the notification is accompanied by an explanation\n of the grounds for the decision in accordance with section 2(1), para (1) of the Act\n and section 171(2) of the Danish Public Procurement Act.
In other situations,\n complaints of award procedures, see section 7(2) of the Act, must be lodged with the\n Danish Complaints Board for Public Procurement before the expiry of:
1) 45 calendar\n days after the contracting entity has published a notice in the Official Journal of\n the European Union that the contracting entity has entered into a contract. The deadline\n is calcu lated from the day after the day when the notice was published.
2)\n 30 calendar days calculated from the day after the day when the contracting entity\n has notified the candidates concerned that a contract based on a framework agreement\n with reopening of competition or a dynamic purchasing system has been entered into\n if the notification has included an explanation of the relevant grounds for the decision.
3)\n 6 months after the contracting entity entered into a framework agreement calculated\n from the day after the day when the contracting entity notified the candidates and\n tenderers concerned, see section 2(2) of the Act and section 171(4) of the Danish\n Public Procurement Act.
4) 20 calendar days calculated from the day after\n the contracting entity has submitted notification of its decision, see section 185(2)\n of the Danish Public Procurement Act.
Not later than at the time of lodging\n a complaint with the Danish Complaints Board for Public Procurement, the complainant\n must notify the contracting entity in writing that a complaint has been lodged with\n the Danish Complaints Board for Public Procurement and whether the complaint was lodged\n during the standstill period, see section 6(4) of the Act. In cases where the complaint\n was not lodged within the standstill period, the complainant must furthermore indicate\n whether a suspensory effect of the complaint has been requested, see section 12(1)\n of the Act.
The e-mail address of the Complaints Board for Public Procurement\n is klfu@naevneneshus.dk.
The Complaints Board’s own complaints procedure\n is available at https://naevneneshus.dk/start-din-klage/klagenaevnet-for-udbud/vejledning/.\n Organisation, der leverer supplerende oplysninger om udbudsproceduren: A/S Storebælt\n Organisation, der sikrer adgang til udbudsdokumenterne offline: A/S Storebælt\n Organisation, der leverer yderligere oplysninger om klageprocedurerne: Konkurrence- og Forbrugerstyrelsen\n \n \n \n 6 ResultaterVærdien af alle kontrakter tildelt i denne bekendtgørelse: 21.127.600 Dansk krone\n 6.1 Resultat delkontrakt-ID: LOT-0000Der er udvalgt mindst én vinder.\n 6.1.2 Oplysninger om vinderneVinder:Officielt navn: Novenco Building & Industry\n \n Tilbud – Identifikator: Purchase of jet fans for the tunnel at the Great Belt Link - Novenco Building & Industry\n ID for delkontrakt eller gruppe af delkontrakter: LOT-0000\n Værdien af tilbuddet: 21.127.600 Dansk krone\n Tilbuddet er et alternativt tilbud: nej\n Underentreprise: Endnu ikke kendte\n Kontraktoplysninger:Identifikator for kontrakten: Purchase of jet fans for the tunnel at the Great Belt Link - Novenco Building & Industry\n Datoen for udvælgelsen af det vindende tilbud: 19-11-2025\n Dato for indgåelse af kontrakten: 10-12-2025\n \n \n \n 6.1.4 Statistiske oplysningerModtagne tilbud og ansøgninger om deltagelse:Type modtagne indgivelser: TilbudAntal modtagne tilbud og ansøgninger om deltagelse: 3\n \n Type modtagne indgivelser: Tilbud, der er indgivet ad elektronisk vejAntal modtagne tilbud og ansøgninger om deltagelse: 3\n \n Type modtagne indgivelser: Tilbud fra mikrovirksomheder samt små eller mellemstore virksomhederAntal modtagne tilbud og ansøgninger om deltagelse: 2\n \n \n \n \n \n 8 Organisationer8.1 ORG-0001Officielt navn: A/S Storebælt\n Registreringsnummer: 10 63 49 70\n Afdeling: Sund & Bælt Holding A/S\n Postadresse: Vester Søgade 10 \n \n \n Landsdel (NUTS): Byen København (DK011)\n \n Enhed: SBF - Mathilde Thulstrup\n \n \n Internetadresse: https://sundogbaelt.dk/om-os/organisering-og-ledelse/a-s-storebaelt/\n Køberprofil: https://eu.eu-supply.com/ctm/company/companyinformation/index/281426\n Denne organisations roller:\n Organisation, der leverer supplerende oplysninger om udbudsproceduren\n Organisation, der sikrer adgang til udbudsdokumenterne offline\n \n \n 8.1 ORG-0002Officielt navn: Klagenævnet for Udbud\n Registreringsnummer: 37795526\n Postadresse: Nævnenes Hus, Toldboden 2 \n \n \n Landsdel (NUTS): Vestjylland (DK041)\n \n E-mail: klfu@naevneneshus.dk\n \n Internetadresse: https://klfu.naevneneshus.dk/\n Denne organisations roller:Organisation med ansvar for klager\n \n \n 8.1 ORG-0003Officielt navn: Konkurrence- og Forbrugerstyrelsen\n Registreringsnummer: 10294819\n Postadresse: Carl Jacobsens Vej 35 \n \n \n Landsdel (NUTS): Byen København (DK011)\n \n \n \n Internetadresse: http://www.kfst.dk\n Denne organisations roller:Organisation, der leverer yderligere oplysninger om klageprocedurerne\n \n \n 8.1 ORG-0004Officielt navn: Novenco Building & Industry\n Den økonomiske operatørs størrelse: Mikrovirksomhed, lille eller mellemstor virksomhed\n Registreringsnummer: DK 16 92 66 47\n Postadresse: Oeverup Erhvervsvej 50-52 \n \n \n Landsdel (NUTS): Vest- og Sydsjælland (DK022)\n \n E-mail: info@novenco-building.com\n \n Denne organisations roller:\n Vinder af disse delkontrakter: LOT-0000\n \n \n 8.1 ORG-0005Officielt navn: Mercell Holding ASA\n Registreringsnummer: 980921565\n Postadresse: Askekroken 11 \n \n \n Landsdel (NUTS): Oslo (NO081)\n \n \n E-mail: publication@mercell.com\n \n \n Internetadresse: http://mercell.com/\n Denne organisations roller:\n \n \n \n Oplysninger om bekendtgørelsenBekendtgørelsens ID: 9fa66f12-f544-4538-96a1-2f946483068f - 01\n \n Bekendtgørelsestype: Bekendtgørelse om indgåede kontrakter eller koncessionstildeling – standardordningen\n Afsendelsesdato for bekendtgørelsen: 12-12-2025 13:13 +00:00\n Dato for afsendelse af bekendtgørelsen (eSender): 12-12-2025 13:30 +00:00\n Bekendtgørelsens officielle sprog: engelsk \n Bekendtgørelsesnummer: 00832208-2025\n \n Offentliggørelsesdato: 15-12-2025\n \n \n","htmlEN":"\n\n \n 1 Buyer1.1 BuyerOfficial name: A/S Storebælt\n Legal type of the buyer: Body governed by public law\n Activity of the contracting authority: Housing and community amenities\n Activity of the contracting entity: Railway services\n \n \n 2 Procedure2.1 ProcedureTitle: Purchase of jet fans for the tunnel at the Great Belt Link\n Description: BACKGROUND:
The 160 jet fans in the railway tunnel on the Great Belt Link is at\n the end-of-life cycle and is required to be replaced. The main purposes of the jet\n fans are to remove smoke during a fire and ventilate for safe working environment.
The\n tunnel is approximately 8 km long and at its deepest point the tunnel is 75 meters\n below sea level.
The tunnel consists of two separate tunnels called the south\n and north tunnel with one railway track in each tunnel. The two tunnels are connected\n by 31 cross tunnels, which partly function as an escape route between the two tunnels\n and partly contain installations, such as switch-boards and transformers.
THE\n SCOPE OF THE TENDER
The scope of this tender is to provide project management,\n design, manufacturing, factory testing (FAT), delivery to site, supervision at site\n and documentation for the new jet fans.
Currently there are 80 jet fans installed\n in each tube, totally 160 jet fans. The new jet fans shall be installed at the same\n location as the existing to minimize the works for power supply and fixtures to the\n concrete. The existing brackets, which is fixed to the concrete wall in the tunnel\n shall be reused for mounting the new jet fans.
The new jet fans will have\n higher capacity than the existing jet fans, but the quantity of jet fans will remain\n the same 80 jet fans per tunnel, totally 160 new jet fans.
The jet fans shall\n be delivered with connected power and control cables connected to minimize the works\n at site.
The installation of the jet fans is done during limited closures\n of the railway tunnel. The installation of the jet fans is not part of the scope of\n this tender. It is part of this tender to provide supervision of the installation\n and testing of all jet fans 24 hours a day during the railway tunnel closures. The\n primary scope of the supervision is to approve the installation and testing done by\n a third party contactor and the secondary scope is to assist if there are issues with\n the supplied jet fans and related equipment supplied in this tender.
The\n installation and testing at site of the jet fans are planned into two main phases.
•\n Phase 1 – July 2026 – Test installation of one jet fan in the tunnel.
• Phase\n 2 – May and June 2027 – Installation and testing of the rest of the jet fans.
Further\n information and details are described in tender material.\n Procedure identifier: 9e4cadb5-6491-4c9b-a436-bab7c710432c\n Previous notice: 1d0299d4-b87c-48c6-b225-778e7f17183f-01\n \n Type of procedure: Restricted\n The procedure is accelerated: no\n 2.1.1 PurposeMain nature of the contract: Supplies\n Main classification (cpv): 42522000 Non-domestic fans\n \n 2.1.2 Place of performancePostal address: Halsskovvej 150 \n \n \n Country subdivision (NUTS): Vest- og Sydsjælland (DK022)\n \n Additional information: The place of delivery of the jet fans is the above address. The supervision will take\n place during the installation, which is in the tunnels at the Great Belt Link.\n \n 2.1.3 ValueEstimated value excluding VAT: 38.000.000 Danish krone\n \n 2.1.4 General informationAdditional information: A/S Storebælt only received non-compliant tenders. Thus, the Contracting Entity chose\n to proceed with a negotiated procedure in accordance with article 50(1)(a) in directive\n 2014/25/EU on procurement by entities operating in the water, energy, transport and\n postal services sectors and repealing Directive 2004/17/EC. The contracting entity\n invited all tenderers to a negotation.
The value stated for the tender is\n stated as the evaluation technical price.\n \n \n Directive 2014/25/EU - The Utilities Directive (Directive 2014/25/EU) is implemented in Danish law by Ministerial\n Order on procurement by entities operating in the water, energy, transport and postal\n services sectors (Ministerial Order No. 1078 of 29 June 2022), which also contains\n supplementary provisions.\n \n \n \n 5 Lot5.1 Lot technical ID: LOT-0000Title: Purchase of jet fans for the tunnel at the Great Belt Link\n Description: BACKGROUND:
The 160 jet fans in the railway tunnel on the Great Belt Link is at\n the end-of-life cycle and is required to be replaced. The main purposes of the jet\n fans are to remove smoke during a fire and ventilate for safe working environment.
The\n tunnel is approximately 8 km long and at its deepest point the tunnel is 75 meters\n below sea level.
The tunnel consists of two separate tunnels called the south\n and north tunnel with one railway track in each tunnel. The two tunnels are connected\n by 31 cross tunnels, which partly function as an escape route between the two tunnels\n and partly contain installations, such as switch-boards and transformers.
THE\n SCOPE OF THE TENDER
The scope of this tender is to provide project management,\n design, manufacturing, factory testing (FAT), delivery to site, supervision at site\n and documentation for the new jet fans.
Currently there are 80 jet fans installed\n in each tube, totally 160 jet fans. The new jet fans shall be installed at the same\n location as the existing to minimize the works for power supply and fixtures to the\n concrete. The existing brackets, which is fixed to the concrete wall in the tunnel\n shall be reused for mounting the new jet fans.
The new jet fans will have\n higher capacity than the existing jet fans, but the quantity of jet fans will remain\n the same 80 jet fans per tunnel, totally 160 new jet fans.
The jet fans shall\n be delivered with connected power and control cables connected to minimize the works\n at site.
The installation of the jet fans is done during limited closures\n of the railway tunnel. The installation of the jet fans is not part of the scope of\n this tender. It is part of this tender to provide supervision of the installation\n and testing of all jet fans 24 hours a day during the railway tunnel closures. The\n primary scope of the supervision is to approve the installation and testing done by\n a third party contactor and the secondary scope is to assist if there are issues with\n the supplied jet fans and related equipment supplied in this tender.
The\n installation and testing at site of the jet fans are planned into two main phases.
•\n Phase 1 – July 2026 – Test installation of one jet fan in the tunnel.
• Phase\n 2 – May and June 2027 – Installation and testing of the rest of the jet fans.
Further\n information and details are described in tender material.\n \n 5.1.1 PurposeMain nature of the contract: Supplies\n Main classification (cpv): 42522000 Non-domestic fans\n \n 5.1.2 Place of performancePostal address: Halsskovvej 150 \n \n \n Country subdivision (NUTS): Vest- og Sydsjælland (DK022)\n \n Additional information: The place of delivery of the jet fans is the above address. The supervision will take\n place during the installation, which is in the tunnels at the Great Belt Link.\n \n 5.1.3 Estimated duration\n \n \n 5.1.5 ValueEstimated value excluding VAT: 38.000.000 Danish krone\n \n 5.1.6 General informationProcurement Project not financed with EU Funds.\n The procurement is covered by the Government Procurement Agreement (GPA): yes\n Additional information: A/S Storebælt only received non-compliant tenders. Thus, the Contracting Entity chose\n to proceed with a negotiated procedure in accordance with article 50(1)(a) in directive\n 2014/25/EU on procurement by entities operating in the water, energy, transport and\n postal services sectors and repealing Directive 2004/17/EC. The contracting entity\n invited all tenderers to a negotation.
The value stated for the tender is\n stated as the evaluation technical price.\n \n 5.1.10 Award criteriaCriterion:\n \n Description: See Tender Specifications section 5.\n Category of award threshold criterion: Weight (percentage, exact)Award criterion number: 70\n \n \n Criterion:\n \n Description: See Tender Specifications section 5.\n Category of award threshold criterion: Weight (percentage, exact)Award criterion number: 15\n \n \n Criterion:\n Name: Climate Change Mitigation Plan\n Description: See Tender Specifications section 5.\n Category of award threshold criterion: Weight (percentage, exact)Award criterion number: 15\n \n \n \n 5.1.15 Techniques\n Information about the dynamic purchasing system:No dynamic purchase system\n \n \n 5.1.16 Further information, mediation and reviewReview organisation: Klagenævnet for Udbud\n Information about review deadlines: Pursuant to the Danish Act on the Complaints Board for Public Procurement, etc. (lov\n om Klagenævnet for Udbud m.v.) (the Act is available (in Danish) at www.retsinformation.dk),\n the following deadlines apply to the lodging of complaints:
Complaints of\n not having been selected must be submitted to the Danish Complaints Board for Public\n Procurement before the expiry of 20 calendar days, see section 7(1) of the Act, from\n the day after submission of notification to the candidates concerned of the identity\n of the successful tenderer where the notification is accompanied by an explanation\n of the grounds for the decision in accordance with section 2(1), para (1) of the Act\n and section 171(2) of the Danish Public Procurement Act.
In other situations,\n complaints of award procedures, see section 7(2) of the Act, must be lodged with the\n Danish Complaints Board for Public Procurement before the expiry of:
1) 45 calendar\n days after the contracting entity has published a notice in the Official Journal of\n the European Union that the contracting entity has entered into a contract. The deadline\n is calcu lated from the day after the day when the notice was published.
2)\n 30 calendar days calculated from the day after the day when the contracting entity\n has notified the candidates concerned that a contract based on a framework agreement\n with reopening of competition or a dynamic purchasing system has been entered into\n if the notification has included an explanation of the relevant grounds for the decision.
3)\n 6 months after the contracting entity entered into a framework agreement calculated\n from the day after the day when the contracting entity notified the candidates and\n tenderers concerned, see section 2(2) of the Act and section 171(4) of the Danish\n Public Procurement Act.
4) 20 calendar days calculated from the day after\n the contracting entity has submitted notification of its decision, see section 185(2)\n of the Danish Public Procurement Act.
Not later than at the time of lodging\n a complaint with the Danish Complaints Board for Public Procurement, the complainant\n must notify the contracting entity in writing that a complaint has been lodged with\n the Danish Complaints Board for Public Procurement and whether the complaint was lodged\n during the standstill period, see section 6(4) of the Act. In cases where the complaint\n was not lodged within the standstill period, the complainant must furthermore indicate\n whether a suspensory effect of the complaint has been requested, see section 12(1)\n of the Act.
The e-mail address of the Complaints Board for Public Procurement\n is klfu@naevneneshus.dk.
The Complaints Board’s own complaints procedure\n is available at https://naevneneshus.dk/start-din-klage/klagenaevnet-for-udbud/vejledning/.\n Organisation providing additional information about the procurement procedure: A/S Storebælt\n Organisation providing offline access to the procurement documents: A/S Storebælt\n Organisation providing more information on the review procedures: Konkurrence- og Forbrugerstyrelsen\n \n \n \n 6 ResultsValue of all contracts awarded in this notice: 21.127.600 Danish krone\n 6.1 Result lot ldentifier: LOT-0000At least one winner was chosen.\n 6.1.2 Information about winnersWinner:Official name: Novenco Building & Industry\n \n Tender identifier: Purchase of jet fans for the tunnel at the Great Belt Link - Novenco Building & Industry\n Identifier of lot or group of lots: LOT-0000\n Value of the tender: 21.127.600 Danish krone\n The tender is a variant: no\n Subcontracting: Not yet known\n Contract information:Identifier of the contract: Purchase of jet fans for the tunnel at the Great Belt Link - Novenco Building & Industry\n Date on which the winner was chosen: 19-11-2025\n Date of the conclusion of the contract: 10-12-2025\n \n \n \n 6.1.4 Statistical informationReceived tenders or requests to participate:Type of received submissions: TendersNumber of tenders or requests to participate received: 3\n \n Type of received submissions: Tenders submitted electronicallyNumber of tenders or requests to participate received: 3\n \n Type of received submissions: Tenders from micro, small or medium tenderersNumber of tenders or requests to participate received: 2\n \n \n \n \n \n 8 Organisations8.1 ORG-0001Official name: A/S Storebælt\n Registration number: 10 63 49 70\n Department: Sund & Bælt Holding A/S\n Postal address: Vester Søgade 10 \n \n \n Country subdivision (NUTS): Byen København (DK011)\n \n Contact point: SBF - Mathilde Thulstrup\n \n Telephone: +45 33 93 52 00\n Internet address: https://sundogbaelt.dk/om-os/organisering-og-ledelse/a-s-storebaelt/\n Buyer profile: https://eu.eu-supply.com/ctm/company/companyinformation/index/281426\n Roles of this organisation:\n Organisation providing additional information about the procurement procedure\n Organisation providing offline access to the procurement documents\n \n \n 8.1 ORG-0002Official name: Klagenævnet for Udbud\n Registration number: 37795526\n Postal address: Nævnenes Hus, Toldboden 2 \n \n \n Country subdivision (NUTS): Vestjylland (DK041)\n \n Email: klfu@naevneneshus.dk\n \n Internet address: https://klfu.naevneneshus.dk/\n Roles of this organisation:\n \n \n 8.1 ORG-0003Official name: Konkurrence- og Forbrugerstyrelsen\n Registration number: 10294819\n Postal address: Carl Jacobsens Vej 35 \n \n \n Country subdivision (NUTS): Byen København (DK011)\n \n \n \n Internet address: http://www.kfst.dk\n Roles of this organisation:Organisation providing more information on the review procedures\n \n \n 8.1 ORG-0004Official name: Novenco Building & Industry\n Size of the economic operator: Micro, small, or medium\n Registration number: DK 16 92 66 47\n Postal address: Oeverup Erhvervsvej 50-52 \n \n \n Country subdivision (NUTS): Vest- og Sydsjælland (DK022)\n \n Email: info@novenco-building.com\n \n Roles of this organisation:\n Winner of these lots: LOT-0000\n \n \n 8.1 ORG-0005Official name: Mercell Holding ASA\n Registration number: 980921565\n Postal address: Askekroken 11 \n \n \n Country subdivision (NUTS): Oslo (NO081)\n \n \n Email: publication@mercell.com\n \n \n Internet address: http://mercell.com/\n Roles of this organisation:\n \n \n \n Notice informationNotice identifier/version: 9fa66f12-f544-4538-96a1-2f946483068f - 01\n \n Notice type: Contract or concession award notice – standard regime\n Notice dispatch date: 12-12-2025 13:13 +00:00\n Notice dispatch date (eSender): 12-12-2025 13:30 +00:00\n Languages in which this notice is officially available: English \n Notice publication number: 00832208-2025\n OJ S issue number: 241/2025\n Publication date: 15-12-2025\n \n \n","opsummeringDA":{"card":{"titel":"Purchase of jet fans for the tunnel at the Great Belt Link","ordregiver":"A/S Storebælt","ordregiverId":"10 63 49 70","ordregiverIdDatavasket":"10634970","publiceringsdato":"2025-12-15+01:00","cpvKode":"42522000","cpvTitel":"Ventilatorer, ikke til privat brug","formulartype":"Resultater","formulartypeKode":"result","tidsfrister":[],"alleOrdregivere":["A/S Storebælt"],"anslaaetVaerdi":"38000000","anslaaetVaerdiValuta":"DKK","beskrivelse":"BACKGROUND:\nThe 160 jet fans in the railway tunnel on the Great Belt Link is at the end-of-life cycle and is required to be replaced. The main purposes of the jet fans are to remove smoke during a fire and ventilate for safe working environment.\n\nThe tunnel is approximately 8 km long and at its deepest point the tunnel is 75 meters below sea level.\n\nThe tunnel consists of two separate tunnels called the south and north tunnel with one railway track in each tunnel. The two tunnels are connected by 31 cross tunnels, which partly function as an escape route between the two tunnels and partly contain installations, such as switch-boards and transformers. \n\nTHE SCOPE OF THE TENDER\nThe scope of this tender is to provide project management, design, manufacturing, factory testing (FAT), delivery to site, supervision at site and documentation for the new jet fans.\n\nCurrently there are 80 jet fans installed in each tube, totally 160 jet fans. The new jet fans shall be installed at the same location as the existing to minimize the works for power supply and fixtures to the concrete. The existing brackets, which is fixed to the concrete wall in the tunnel shall be reused for mounting the new jet fans.\n\nThe new jet fans will have higher capacity than the existing jet fans, but the quantity of jet fans will remain the same 80 jet fans per tunnel, totally 160 new jet fans.\n\nThe jet fans shall be delivered with connected power and control cables connected to minimize the works at site. \n\nThe installation of the jet fans is done during limited closures of the railway tunnel. The installation of the jet fans is not part of the scope of this tender. It is part of this tender to provide supervision of the installation and testing of all jet fans 24 hours a day during the railway tunnel closures. The primary scope of the supervision is to approve the installation and testing done by a third party contactor and the secondary scope is to assist if there are issues with the supplied jet fans and related equipment supplied in this tender.\n\nThe installation and testing at site of the jet fans are planned into two main phases.\n• Phase 1 – July 2026 – Test installation of one jet fan in the tunnel.\n• Phase 2 – May and June 2027 – Installation and testing of the rest of the jet fans.\n\nFurther information and details are described in tender material.","bkSubTypeKode":"30","bkSubType":"Bekendtgørelse om indgåede kontrakter – sektordirektivet, standardordningen","erAendring":false},"indholdsType":"HENTET_FRA_TED","sekundaereOrdregivere":[],"udforelsesstedNutsCode":["DK022"],"udforelsesstedSubLand":["Vest- og Sydsjælland"],"udforelsesstedLand":["Danmark"],"udforelsesstedBy":["Korsør"],"tilbudsfrister":[],"intressentfrister":[],"deltagelsefrister":[],"svarfrister":[],"antalParts":0,"antalLots":1,"udbudsDokumenter":[]},"opsummeringEN":{"card":{"titel":"Purchase of jet fans for the tunnel at the Great Belt Link","ordregiver":"A/S Storebælt","ordregiverId":"10 63 49 70","ordregiverIdDatavasket":"10634970","publiceringsdato":"2025-12-15+01:00","cpvKode":"42522000","cpvTitel":"Non-domestic fans","formulartype":"Result","formulartypeKode":"result","tidsfrister":[],"alleOrdregivere":["A/S Storebælt"],"anslaaetVaerdi":"38000000","anslaaetVaerdiValuta":"DKK","beskrivelse":"BACKGROUND:\nThe 160 jet fans in the railway tunnel on the Great Belt Link is at the end-of-life cycle and is required to be replaced. The main purposes of the jet fans are to remove smoke during a fire and ventilate for safe working environment.\n\nThe tunnel is approximately 8 km long and at its deepest point the tunnel is 75 meters below sea level.\n\nThe tunnel consists of two separate tunnels called the south and north tunnel with one railway track in each tunnel. The two tunnels are connected by 31 cross tunnels, which partly function as an escape route between the two tunnels and partly contain installations, such as switch-boards and transformers. \n\nTHE SCOPE OF THE TENDER\nThe scope of this tender is to provide project management, design, manufacturing, factory testing (FAT), delivery to site, supervision at site and documentation for the new jet fans.\n\nCurrently there are 80 jet fans installed in each tube, totally 160 jet fans. The new jet fans shall be installed at the same location as the existing to minimize the works for power supply and fixtures to the concrete. The existing brackets, which is fixed to the concrete wall in the tunnel shall be reused for mounting the new jet fans.\n\nThe new jet fans will have higher capacity than the existing jet fans, but the quantity of jet fans will remain the same 80 jet fans per tunnel, totally 160 new jet fans.\n\nThe jet fans shall be delivered with connected power and control cables connected to minimize the works at site. \n\nThe installation of the jet fans is done during limited closures of the railway tunnel. The installation of the jet fans is not part of the scope of this tender. It is part of this tender to provide supervision of the installation and testing of all jet fans 24 hours a day during the railway tunnel closures. The primary scope of the supervision is to approve the installation and testing done by a third party contactor and the secondary scope is to assist if there are issues with the supplied jet fans and related equipment supplied in this tender.\n\nThe installation and testing at site of the jet fans are planned into two main phases.\n• Phase 1 – July 2026 – Test installation of one jet fan in the tunnel.\n• Phase 2 – May and June 2027 – Installation and testing of the rest of the jet fans.\n\nFurther information and details are described in tender material.","bkSubTypeKode":"30","bkSubType":"Contract award notice – sectoral directive, standard regime","erAendring":false},"indholdsType":"HENTET_FRA_TED","sekundaereOrdregivere":[],"udforelsesstedNutsCode":["DK022"],"udforelsesstedSubLand":["Vest- og Sydsjælland"],"udforelsesstedLand":["Denmark"],"udforelsesstedBy":["Korsør"],"tilbudsfrister":[],"intressentfrister":[],"deltagelsefrister":[],"svarfrister":[],"antalParts":0,"antalLots":1,"udbudsDokumenter":[]}}