{"bekendtgoerelseNoegle":{"noticeId":{"value":"25298cf4-5534-4f99-804f-d1710b248e36"},"noticeVersion":{"value":"01"},"noticePublicationNumber":{"value":"00324409-2025"}},"htmlDA":"\n\n \n
1 Køber
1.1 Køber
Officielt navn: Assens Municipality
\n
Køberens retlige status: Lokal myndighed
\n
Den ordregivende myndigheds aktivitet: Generelle offentlige tjenesteydelser
\n
\n
\n
2 Procedure
2.1 Procedure
Titel: RE-TENDER - Centre for Coastal Nature and Sport Fishing, Assens Harbour (dissemination)
\n
Beskrivelse: The present re-tender deals with concept proposals for exhibition and experience design\n at the National Centre for Coastal Nature and Sport Fishing at the Middle Pier at\n Assens Harbour. The project is tendered as a turnkey contract.
The Centre for\n Coastal Nature and Sport Fishing will be an experience centre which, through experiences\n and stories about the sea, coasts, lakes, streams, fish and angling, will make visitors\n marvel at life beneath the water's surface, and which will make visitors want to try\n their hand at unique nature experiences.
We are looking for a turnkey contractor\n who can deliver a strong and inspiring concept, thereby creating an attraction of\n international class.
A concluded design competition has defined the building framework\n for the centre, which will have a beautiful location in the transition between the\n market town (Assens), the coast (the Little Belt) and the coastal landscapes (the\n Funen archipelago). The centre is expected to open spring 2027.
Reference is also\n made to the tender documents, which comprise a detailed description of the project.
\n
Identifikator for proceduren: 3eea7c84-d2d9-40c3-86c6-fee54dac67f6
\n
Tidligere bekendtgørelse: 537545-2024
\n
Udbudsprocedure: Begrænset
\n
Proceduren er en hasteprocedure: nej
\n
Hovedpunkterne i proceduren: The tender is conducted as a restricted tender in accordance with the Public Procurement\n Act §§ 58-60. This procurement procedure involves dividing the process into two phases:\n (i) a prequalification phase and (ii) a tender phase. In the initial prequalification\n phase, any company can apply for prequalification on the basis of the tender notice.\n After the application deadline, the Client will select the companies that are best\n suited to submit tenders for the task. In the subsequent tender phase, the applicants\n selected by the Client in the prequalification phase will be invited to submit a tender\n for the project by submitting a proposed solution.
\n
2.1.1 Formål
Kontraktens hovedformål: Bygge og anlæg
\n
Primær klassifikation (cpv): 45000000 Bygge- og anlægsarbejder
\n
Supplerende klassifikation (cpv): 71200000 Arkitektvirksomhed samt hermed beslægtet virksomhed
\n
Supplerende klassifikation (cpv): 92520000 Museer og beslægtet virksomhed
\n
Supplerende klassifikation (cpv): 92521100 Udstilling på museer
\n
Supplerende klassifikation (cpv): 71530000 Rådgivning i forbindelse med byggeri
\n
Supplerende klassifikation (cpv): 32321200 Av-udstyr
\n
Supplerende klassifikation (cpv): 39154000 Udstillingsudstyr
\n
\n
2.1.2 Udførelsessted
Postadresse: Nordre Havnevej  
\n
By: Assens
\n
Postnummer: 5610
\n
Landsdel (NUTS): Fyn (DK031)
\n
Land: Danmark
\n
\n
2.1.3 Værdi
Anslået værdi eksklusiv moms: 15.500.000 Dansk krone
\n
\n
2.1.4 Generelle oplysninger
Yderligere oplysninger: Pursuant to section 134a of the Danish Public Procurement Act, the Client must exclude\n a candidate or tenderer from participation in the tender procedure if the applicant\n or tenderer is established in a country that is included on the EU list of non-cooperative\n tax jurisdictions and has not acceded to the WTO's Government Procurement Agreement\n or other trade agreements obliging Denmark to open the market for public contracts\n to tenderers established in that particular country. The client will ensure the absence\n of the exclusion ground prior to the award decision. The client further draws attention\n to the fact that pursuant to Article 5k of Council Regulation (EU) 2022/576 of 8 April\n 2022 amending Regulation (EU) No 833/2014 concerning restrictive measures in view\n of Russia's actions destabilising the situation in Ukraine ('the Regulation'), a ban\n on awarding contracts to Russian companies and Russian-controlled companies, etc.\n applies. The prohibition also applies to the award of contracts to tenderers using\n supporting entities or sub-consultants covered by Article 5k of the Regulation if\n the value of the deliveries of such a supporting entity or sub-consultant accounts\n for more than 10 % of the value of the contract. The client may therefore, at any\n stage of the procurement process, require applicants and tenderers to document that\n they are not in a situation falling within the scope of Article 5k of the Regulation.\n In this connection, the Client may ask candidates or tenderers to sign the declaration\n of honour attached to the tender documents regarding the absence of this connection.
\n
Retsgrundlag:
\n
Direktiv 2014/24/EU
\n
\n
\n
\n
5 Delkontrakt
5.1 Teknisk ID for delkontrakten: LOT-0001
Titel: RE-TENDER - Centre for Coastal Nature and Sport Fishing, Assens Harbour (dissemination)
\n
Beskrivelse: The present re-tender deals with concept proposals for exhibition and experience design\n at the National Centre for Coastal Nature and Sport Fishing at the Middle Pier at\n Assens Harbour. The project is tendered as a turnkey contract.
The Centre for\n Coastal Nature and Sport Fishing will be an experience centre which, through experiences\n and stories about the sea, coasts, lakes, streams, fish and angling, will make visitors\n marvel at life beneath the water's surface, and which will make visitors want to try\n their hand at unique nature experiences.
We are looking for a turnkey contractor\n who can deliver a strong and inspiring concept, thereby creating an attraction of\n international class.
A concluded design competition has defined the building framework\n for the centre, which will have a beautiful location in the transition between the\n market town (Assens), the coast (the Little Belt) and the coastal landscapes (the\n Funen archipelago). The centre is expected to open spring 2027.
Reference is also\n made to the tender documents, which comprise a detailed description of the project.
\n
Intern ID: 1
\n
5.1.1 Formål
Kontraktens hovedformål: Bygge og anlæg
\n
Primær klassifikation (cpv): 45000000 Bygge- og anlægsarbejder
\n
Supplerende klassifikation (cpv): 71200000 Arkitektvirksomhed samt hermed beslægtet virksomhed
\n
Supplerende klassifikation (cpv): 92520000 Museer og beslægtet virksomhed
\n
Supplerende klassifikation (cpv): 92521100 Udstilling på museer
\n
Supplerende klassifikation (cpv): 71530000 Rådgivning i forbindelse med byggeri
\n
Supplerende klassifikation (cpv): 32321200 Av-udstyr
\n
Supplerende klassifikation (cpv): 39154000 Udstillingsudstyr
\n
\n
5.1.2 Udførelsessted
Postadresse: Nordre Havnevej  
\n
By: Assens
\n
Postnummer: 5610
\n
Landsdel (NUTS): Fyn (DK031)
\n
Land: Danmark
\n
Yderligere oplysninger: The centre will be established at the Middle Pier, Assens Harbour
\n
\n
5.1.3 Anslået varighed
Varighed: 30 Måned
\n
\n
5.1.6 Generelle oplysninger
Indkøbsprojekt, der ikke finansieres med EU-midler
\n
Udbuddet er omfattet af aftalen om offentlige udbud (GPA): ja
\n
Yderligere oplysninger: In accordance with section 49(2) of the Danish Public Procurement Act, the client\n has considered dividing the contract into two parts. In this connection, it is the\n Client's assessment that the realisation of the tendered project can be carried out\n most appropriately in two separate agreements: A consultancy contract for the design\n of the centre's buildings and its facilities, and a turnkey contract for the dissemination\n of the centre and its exhibitions. The present turnkey competition only concerns the\n dissemination in the turnkey of the centre's buildings and the facilities and hotspots\n located along the harbour.
\n
\n
5.1.10 Tildelingskriterier
Kriterium:
Type: Kvalitet
\n
Beskrivelse: Exhibition concept
\n
Kategori for tildelingskriteriet tærskel: Vægtning (procentdel, præcis)
Tildelingskriterium talværdi: 60
\n
\n
\n
Kriterium:
Type: Kvalitet
\n
Beskrivelse: Functionality
\n
Kategori for tildelingskriteriet tærskel: Vægtning (procentdel, præcis)
Tildelingskriterium talværdi: 25
\n
\n
\n
Kriterium:
Type: Kvalitet
\n
Beskrivelse: Experience and organisation
\n
Kategori for tildelingskriteriet tærskel: Vægtning (procentdel, præcis)
Tildelingskriterium talværdi: 15
\n
\n
\n
\n
5.1.15 Teknikker
Rammeaftale:
Ingen rammeaftale
\n
\n
Oplysninger om det dynamiske indkøbssystem:
Intet dynamisk indkøbssystem
\n
\n
\n
5.1.16 Yderligere oplysninger, mægling og gennemgang
Organisation med ansvar for klager: Danish Complaints Board for Public Procurement
\n
Oplysninger om klagefrister: According to the Act on the Danish Complaints Board for Public Procurement, the following\n deadlines apply for filing a complaint: * Complaints about not having been prequalified\n must be submitted to the Danish Complaints Board for Public Procurement within 20\n calendar days from the day following the sending of a notification to the affected\n applicants of who has been selected, cf. section 171 of the Danish Public Procurement\n Act, (2) or Section 2(1)(1) of the Danish Complaints Board Act, where the notification\n is accompanied by a statement of reasons for the decision. In other situations, an\n complaint against a call for competition must be filed with the Danish Complaints\n Board for Public Procurement before: (1) 45 calendar days after the contracting entity\n has published a notice in the Official Journal of the European Union announcing the\n award of a contract. The period shall begin on the day following that on which the\n notice was published. (2) 30 calendar days from the day following that on which the\n contracting entity notifies the tenderers concerned that a contract based on a framework\n agreement reopening competition or a dynamic purchasing system has been awarded, if\n the notification has given reasons for the decision. (3) six months after the contracting\n entity has concluded a framework agreement, counting from the day following the day\n on which the contracting entity notifies the candidates and tenderers concerned, cf.\n section 2(2) of the Danish Complaints Board Act or section 171(2) of the Danish Public\n Procurement Act.
4. (4) 20 calendar days from the day after the contracting entity\n has notified its decision, cf. section 185(2) of the Danish Public Procurement Act.\n At the latest at the same time as a complaint is filed with the Danish Complaints\n Board for Public Procurement, the complainant shall inform in writing the contracting\n entity that the complaint be submitted to the Danish Complaints Board for Public Procurement\n and whether the complaint was filed during the standstill period, cf. section 6(4)\n of the Danish Complaints Board Act. In cases where the complaint has not been filed\n during the standstill period, the complainant must also state whether suspensive effect\n of the complaint is requested, cf. section 12(1) of the Danish Complaints Board Act.\n At the same time as filing a complaint, a complaint fee of DKK 20,000 must be paid\n to the Danish Complaints Board for Public Procurement.
\n
Organisation, der leverer yderligere oplysninger om klageprocedurerne: Danish Competition and Consumer Authority
\n
\n
\n
\n
6 Resultater
Værdien af alle kontrakter tildelt i denne bekendtgørelse: 15.500.000 Dansk krone
\n
6.1 Resultat delkontrakt-ID: LOT-0001
Der er udvalgt mindst én vinder.
\n
6.1.2 Oplysninger om vinderne
Vinder:
Officielt navn: TRIAS AVI SPÓŁKA Z OGRANICZONĄ ODPOWIEDZIALNOŚCIĄ
\n
Tilbud:
\n
Tilbud – Identifikator: Konkurrenceforslag
\n
ID for delkontrakt eller gruppe af delkontrakter: LOT-0001
\n
Værdien af tilbuddet: 15.500.000 Dansk krone
\n
Tilbuddet er et alternativt tilbud: nej
\n
Underentreprise: Nej
\n
Kontraktoplysninger:
Identifikator for kontrakten: Indgået kontrakt
\n
Datoen for udvælgelsen af det vindende tilbud: 18-12-2024
\n
Dato for indgåelse af kontrakten: 27-03-2025
\n
\n
\n
\n
6.1.4 Statistiske oplysninger
Modtagne tilbud og ansøgninger om deltagelse:
Type modtagne indgivelser: Tilbud fra mikrovirksomheder samt små eller mellemstore virksomheder
Antal modtagne tilbud og ansøgninger om deltagelse: 5
\n
\n
Type modtagne indgivelser: Tilbud fra tilbudsgivere, der er registreret i andre EØS-lande end købers land
Antal modtagne tilbud og ansøgninger om deltagelse: 4
\n
\n
Type modtagne indgivelser: Tilbud fra tilbudsgivere, der er registreret i lande uden for EØS
Antal modtagne tilbud og ansøgninger om deltagelse: 1
\n
\n
Type modtagne indgivelser: Tilbud
Antal modtagne tilbud og ansøgninger om deltagelse: 5
\n
\n
Type modtagne indgivelser: Tilbud, der er indgivet ad elektronisk vej
Antal modtagne tilbud og ansøgninger om deltagelse: 5
\n
\n
\n
\n
\n
\n
8 Organisationer
8.1 ORG-0001
Officielt navn: Assens Municipality
\n
Registreringsnummer: 29189692
\n
Postadresse: Rådhus Allé 5  
\n
By: Assens
\n
Postnummer: 5610
\n
Landsdel (NUTS): Fyn (DK031)
\n
Land: Danmark
\n
Enhed: Rasmus Kirk Christensen
\n
E-mail: rakc@ramboll.dk
\n
Telefon: +45 51613982
\n
Internetadresse: https://www.assens.dk/
\n
Denne organisations roller:
Køber
\n
\n
\n
8.1 ORG-0002
Officielt navn: Danish Complaints Board for Public Procurement
\n
Registreringsnummer: 37795526
\n
Postadresse: Nævnenes Hus, Toldboden 2  
\n
By: Viborg
\n
Postnummer: 8800
\n
Landsdel (NUTS): Østjylland (DK042)
\n
Land: Danmark
\n
E-mail: klfu@naevneneshus.dk
\n
Telefon: +45 72405600
\n
Internetadresse: https://naevneneshus.dk/start-din-klage/klagenaevnet-for-udbud/
\n
Denne organisations roller:
Organisation med ansvar for klager
\n
\n
\n
8.1 ORG-0003
Officielt navn: Danish Competition and Consumer Authority
\n
Registreringsnummer: 10294819
\n
Postadresse: Carl Jacobsens Vej 35  
\n
By: Valby
\n
Postnummer: 2500
\n
Landsdel (NUTS): Byen København (DK011)
\n
Land: Danmark
\n
E-mail: kfst@kfst.dk
\n
Telefon: +45 41715000
\n
Internetadresse: https://kfst.dk/
\n
Denne organisations roller:
Organisation, der leverer yderligere oplysninger om klageprocedurerne
\n
\n
\n
8.1 ORG-0004
Officielt navn: TRIAS AVI SPÓŁKA Z OGRANICZONĄ ODPOWIEDZIALNOŚCIĄ
\n
Den økonomiske operatørs størrelse: Mikrovirksomhed, lille eller mellemstor virksomhed
\n
Registreringsnummer: 1080013783
\n
Postadresse: 21 Kabaretowa st.  
\n
By: Warsaw
\n
Postnummer: 01-942
\n
Landsdel (NUTS): Miasto Warszawa (PL911)
\n
Land: Danmark
\n
E-mail: sprzedaz@trias.pl
\n
Telefon: +48 22 839 49 35
\n
Internetadresse: https://www.trias.pl/
\n
Denne organisations roller:
Tilbudsgiver
\n
Vinder af disse delkontrakter: LOT-0001
\n
\n
\n
8.1 ORG-0000
Officielt navn: Publications Office of the European Union
\n
Registreringsnummer: PUBL
\n
By: Luxembourg
\n
Postnummer: 2417
\n
Landsdel (NUTS): Luxembourg (LU000)
\n
Land: Luxembourg
\n
E-mail: ted@publications.europa.eu
\n
Telefon: +352 29291
\n
Internetadresse: https://op.europa.eu
\n
Denne organisations roller:
TED eSender
\n
\n
\n
\n
Oplysninger om bekendtgørelsen
Bekendtgørelsens ID: 25298cf4-5534-4f99-804f-d1710b248e36 - 01
\n
Formulartype: Resultater
\n
Bekendtgørelsestype: Bekendtgørelse om indgåede kontrakter eller koncessionstildeling – standardordningen
\n
Afsendelsesdato for bekendtgørelsen: 19-05-2025 07:57 +00:00
\n
Bekendtgørelsens officielle sprog: engelsk 
\n
Bekendtgørelsesnummer: 00324409-2025
\n
EUT-S-nummer: 96/2025
\n
Offentliggørelsesdato: 20-05-2025
\n
\n \n","htmlEN":"\n\n \n
1 Buyer
1.1 Buyer
Official name: Assens Municipality
\n
Legal type of the buyer: Local authority
\n
Activity of the contracting authority: General public services
\n
\n
\n
2 Procedure
2.1 Procedure
Title: RE-TENDER - Centre for Coastal Nature and Sport Fishing, Assens Harbour (dissemination)
\n
Description: The present re-tender deals with concept proposals for exhibition and experience design\n at the National Centre for Coastal Nature and Sport Fishing at the Middle Pier at\n Assens Harbour. The project is tendered as a turnkey contract.
The Centre for\n Coastal Nature and Sport Fishing will be an experience centre which, through experiences\n and stories about the sea, coasts, lakes, streams, fish and angling, will make visitors\n marvel at life beneath the water's surface, and which will make visitors want to try\n their hand at unique nature experiences.
We are looking for a turnkey contractor\n who can deliver a strong and inspiring concept, thereby creating an attraction of\n international class.
A concluded design competition has defined the building framework\n for the centre, which will have a beautiful location in the transition between the\n market town (Assens), the coast (the Little Belt) and the coastal landscapes (the\n Funen archipelago). The centre is expected to open spring 2027.
Reference is also\n made to the tender documents, which comprise a detailed description of the project.
\n
Procedure identifier: 3eea7c84-d2d9-40c3-86c6-fee54dac67f6
\n
Previous notice: 537545-2024
\n
Type of procedure: Restricted
\n
The procedure is accelerated: no
\n
Main features of the procedure: The tender is conducted as a restricted tender in accordance with the Public Procurement\n Act §§ 58-60. This procurement procedure involves dividing the process into two phases:\n (i) a prequalification phase and (ii) a tender phase. In the initial prequalification\n phase, any company can apply for prequalification on the basis of the tender notice.\n After the application deadline, the Client will select the companies that are best\n suited to submit tenders for the task. In the subsequent tender phase, the applicants\n selected by the Client in the prequalification phase will be invited to submit a tender\n for the project by submitting a proposed solution.
\n
2.1.1 Purpose
Main nature of the contract: Works
\n
Main classification (cpv): 45000000 Construction work
\n
Additional classification (cpv): 71200000 Architectural and related services
\n
Additional classification (cpv): 92520000 Museum services and preservation services of historical sites and buildings
\n
Additional classification (cpv): 92521100 Museum-exhibition services
\n
Additional classification (cpv): 71530000 Construction consultancy services
\n
Additional classification (cpv): 32321200 Audio-visual equipment
\n
Additional classification (cpv): 39154000 Exhibition equipment
\n
\n
2.1.2 Place of performance
Postal address: Nordre Havnevej  
\n
Town: Assens
\n
Postcode: 5610
\n
Country subdivision (NUTS): Fyn (DK031)
\n
Country: Denmark
\n
\n
2.1.3 Value
Estimated value excluding VAT: 15.500.000 Danish krone
\n
\n
2.1.4 General information
Additional information: Pursuant to section 134a of the Danish Public Procurement Act, the Client must exclude\n a candidate or tenderer from participation in the tender procedure if the applicant\n or tenderer is established in a country that is included on the EU list of non-cooperative\n tax jurisdictions and has not acceded to the WTO's Government Procurement Agreement\n or other trade agreements obliging Denmark to open the market for public contracts\n to tenderers established in that particular country. The client will ensure the absence\n of the exclusion ground prior to the award decision. The client further draws attention\n to the fact that pursuant to Article 5k of Council Regulation (EU) 2022/576 of 8 April\n 2022 amending Regulation (EU) No 833/2014 concerning restrictive measures in view\n of Russia's actions destabilising the situation in Ukraine ('the Regulation'), a ban\n on awarding contracts to Russian companies and Russian-controlled companies, etc.\n applies. The prohibition also applies to the award of contracts to tenderers using\n supporting entities or sub-consultants covered by Article 5k of the Regulation if\n the value of the deliveries of such a supporting entity or sub-consultant accounts\n for more than 10 % of the value of the contract. The client may therefore, at any\n stage of the procurement process, require applicants and tenderers to document that\n they are not in a situation falling within the scope of Article 5k of the Regulation.\n In this connection, the Client may ask candidates or tenderers to sign the declaration\n of honour attached to the tender documents regarding the absence of this connection.
\n
Legal basis:
\n
Directive 2014/24/EU
\n
\n
\n
\n
5 Lot
5.1 Lot technical ID: LOT-0001
Title: RE-TENDER - Centre for Coastal Nature and Sport Fishing, Assens Harbour (dissemination)
\n
Description: The present re-tender deals with concept proposals for exhibition and experience design\n at the National Centre for Coastal Nature and Sport Fishing at the Middle Pier at\n Assens Harbour. The project is tendered as a turnkey contract.
The Centre for\n Coastal Nature and Sport Fishing will be an experience centre which, through experiences\n and stories about the sea, coasts, lakes, streams, fish and angling, will make visitors\n marvel at life beneath the water's surface, and which will make visitors want to try\n their hand at unique nature experiences.
We are looking for a turnkey contractor\n who can deliver a strong and inspiring concept, thereby creating an attraction of\n international class.
A concluded design competition has defined the building framework\n for the centre, which will have a beautiful location in the transition between the\n market town (Assens), the coast (the Little Belt) and the coastal landscapes (the\n Funen archipelago). The centre is expected to open spring 2027.
Reference is also\n made to the tender documents, which comprise a detailed description of the project.
\n
Internal identifier: 1
\n
5.1.1 Purpose
Main nature of the contract: Works
\n
Main classification (cpv): 45000000 Construction work
\n
Additional classification (cpv): 71200000 Architectural and related services
\n
Additional classification (cpv): 92520000 Museum services and preservation services of historical sites and buildings
\n
Additional classification (cpv): 92521100 Museum-exhibition services
\n
Additional classification (cpv): 71530000 Construction consultancy services
\n
Additional classification (cpv): 32321200 Audio-visual equipment
\n
Additional classification (cpv): 39154000 Exhibition equipment
\n
\n
5.1.2 Place of performance
Postal address: Nordre Havnevej  
\n
Town: Assens
\n
Postcode: 5610
\n
Country subdivision (NUTS): Fyn (DK031)
\n
Country: Denmark
\n
Additional information: The centre will be established at the Middle Pier, Assens Harbour
\n
\n
5.1.3 Estimated duration
Duration: 30 Month
\n
\n
5.1.6 General information
Procurement Project not financed with EU Funds.
\n
The procurement is covered by the Government Procurement Agreement (GPA): yes
\n
Additional information: In accordance with section 49(2) of the Danish Public Procurement Act, the client\n has considered dividing the contract into two parts. In this connection, it is the\n Client's assessment that the realisation of the tendered project can be carried out\n most appropriately in two separate agreements: A consultancy contract for the design\n of the centre's buildings and its facilities, and a turnkey contract for the dissemination\n of the centre and its exhibitions. The present turnkey competition only concerns the\n dissemination in the turnkey of the centre's buildings and the facilities and hotspots\n located along the harbour.
\n
\n
5.1.10 Award criteria
Criterion:
Type: Quality
\n
Description: Exhibition concept
\n
Category of award threshold criterion: Weight (percentage, exact)
Award criterion number: 60
\n
\n
\n
Criterion:
Type: Quality
\n
Description: Functionality
\n
Category of award threshold criterion: Weight (percentage, exact)
Award criterion number: 25
\n
\n
\n
Criterion:
Type: Quality
\n
Description: Experience and organisation
\n
Category of award threshold criterion: Weight (percentage, exact)
Award criterion number: 15
\n
\n
\n
\n
5.1.15 Techniques
Framework agreement:
No framework agreement
\n
\n
Information about the dynamic purchasing system:
No dynamic purchase system
\n
\n
\n
5.1.16 Further information, mediation and review
Review organisation: Danish Complaints Board for Public Procurement
\n
Information about review deadlines: According to the Act on the Danish Complaints Board for Public Procurement, the following\n deadlines apply for filing a complaint: * Complaints about not having been prequalified\n must be submitted to the Danish Complaints Board for Public Procurement within 20\n calendar days from the day following the sending of a notification to the affected\n applicants of who has been selected, cf. section 171 of the Danish Public Procurement\n Act, (2) or Section 2(1)(1) of the Danish Complaints Board Act, where the notification\n is accompanied by a statement of reasons for the decision. In other situations, an\n complaint against a call for competition must be filed with the Danish Complaints\n Board for Public Procurement before: (1) 45 calendar days after the contracting entity\n has published a notice in the Official Journal of the European Union announcing the\n award of a contract. The period shall begin on the day following that on which the\n notice was published. (2) 30 calendar days from the day following that on which the\n contracting entity notifies the tenderers concerned that a contract based on a framework\n agreement reopening competition or a dynamic purchasing system has been awarded, if\n the notification has given reasons for the decision. (3) six months after the contracting\n entity has concluded a framework agreement, counting from the day following the day\n on which the contracting entity notifies the candidates and tenderers concerned, cf.\n section 2(2) of the Danish Complaints Board Act or section 171(2) of the Danish Public\n Procurement Act.
4. (4) 20 calendar days from the day after the contracting entity\n has notified its decision, cf. section 185(2) of the Danish Public Procurement Act.\n At the latest at the same time as a complaint is filed with the Danish Complaints\n Board for Public Procurement, the complainant shall inform in writing the contracting\n entity that the complaint be submitted to the Danish Complaints Board for Public Procurement\n and whether the complaint was filed during the standstill period, cf. section 6(4)\n of the Danish Complaints Board Act. In cases where the complaint has not been filed\n during the standstill period, the complainant must also state whether suspensive effect\n of the complaint is requested, cf. section 12(1) of the Danish Complaints Board Act.\n At the same time as filing a complaint, a complaint fee of DKK 20,000 must be paid\n to the Danish Complaints Board for Public Procurement.
\n
Organisation providing more information on the review procedures: Danish Competition and Consumer Authority
\n
\n
\n
\n
6 Results
Value of all contracts awarded in this notice: 15.500.000 Danish krone
\n
6.1 Result lot ldentifier: LOT-0001
At least one winner was chosen.
\n
6.1.2 Information about winners
Winner:
Official name: TRIAS AVI SPÓŁKA Z OGRANICZONĄ ODPOWIEDZIALNOŚCIĄ
\n
Tender:
\n
Tender identifier: Konkurrenceforslag
\n
Identifier of lot or group of lots: LOT-0001
\n
Value of the tender: 15.500.000 Danish krone
\n
The tender is a variant: no
\n
Subcontracting: No
\n
Contract information:
Identifier of the contract: Indgået kontrakt
\n
Date on which the winner was chosen: 18-12-2024
\n
Date of the conclusion of the contract: 27-03-2025
\n
\n
\n
\n
6.1.4 Statistical information
Received tenders or requests to participate:
Type of received submissions: Tenders from micro, small or medium tenderers
Number of tenders or requests to participate received: 5
\n
\n
Type of received submissions: Tenders from tenderers registered in other European Economic Area countries than the country of the buyer
Number of tenders or requests to participate received: 4
\n
\n
Type of received submissions: Tenders from tenders registered in countries outside of the European Economic Area
Number of tenders or requests to participate received: 1
\n
\n
Type of received submissions: Tenders
Number of tenders or requests to participate received: 5
\n
\n
Type of received submissions: Tenders submitted electronically
Number of tenders or requests to participate received: 5
\n
\n
\n
\n
\n
\n
8 Organisations
8.1 ORG-0001
Official name: Assens Municipality
\n
Registration number: 29189692
\n
Postal address: Rådhus Allé 5  
\n
Town: Assens
\n
Postcode: 5610
\n
Country subdivision (NUTS): Fyn (DK031)
\n
Country: Denmark
\n
Contact point: Rasmus Kirk Christensen
\n
Email: rakc@ramboll.dk
\n
Telephone: +45 51613982
\n
Internet address: https://www.assens.dk/
\n
Roles of this organisation:
Buyer
\n
\n
\n
8.1 ORG-0002
Official name: Danish Complaints Board for Public Procurement
\n
Registration number: 37795526
\n
Postal address: Nævnenes Hus, Toldboden 2  
\n
Town: Viborg
\n
Postcode: 8800
\n
Country subdivision (NUTS): Østjylland (DK042)
\n
Country: Denmark
\n
Email: klfu@naevneneshus.dk
\n
Telephone: +45 72405600
\n
Internet address: https://naevneneshus.dk/start-din-klage/klagenaevnet-for-udbud/
\n
Roles of this organisation:
Review organisation
\n
\n
\n
8.1 ORG-0003
Official name: Danish Competition and Consumer Authority
\n
Registration number: 10294819
\n
Postal address: Carl Jacobsens Vej 35  
\n
Town: Valby
\n
Postcode: 2500
\n
Country subdivision (NUTS): Byen København (DK011)
\n
Country: Denmark
\n
Email: kfst@kfst.dk
\n
Telephone: +45 41715000
\n
Internet address: https://kfst.dk/
\n
Roles of this organisation:
Organisation providing more information on the review procedures
\n
\n
\n
8.1 ORG-0004
Official name: TRIAS AVI SPÓŁKA Z OGRANICZONĄ ODPOWIEDZIALNOŚCIĄ
\n
Size of the economic operator: Micro, small, or medium
\n
Registration number: 1080013783
\n
Postal address: 21 Kabaretowa st.  
\n
Town: Warsaw
\n
Postcode: 01-942
\n
Country subdivision (NUTS): Miasto Warszawa (PL911)
\n
Country: Denmark
\n
Email: sprzedaz@trias.pl
\n
Telephone: +48 22 839 49 35
\n
Internet address: https://www.trias.pl/
\n
Roles of this organisation:
Tenderer
\n
Winner of these lots: LOT-0001
\n
\n
\n
8.1 ORG-0000
Official name: Publications Office of the European Union
\n
Registration number: PUBL
\n
Town: Luxembourg
\n
Postcode: 2417
\n
Country subdivision (NUTS): Luxembourg (LU000)
\n
Country: Luxembourg
\n
Email: ted@publications.europa.eu
\n
Telephone: +352 29291
\n
Internet address: https://op.europa.eu
\n
Roles of this organisation:
TED eSender
\n
\n
\n
\n
Notice information
Notice identifier/version: 25298cf4-5534-4f99-804f-d1710b248e36 - 01
\n
Form type: Result
\n
Notice type: Contract or concession award notice – standard regime
\n
Notice dispatch date: 19-05-2025 07:57 +00:00
\n
Languages in which this notice is officially available: English 
\n
Notice publication number: 00324409-2025
\n
OJ S issue number: 96/2025
\n
Publication date: 20-05-2025
\n
\n \n","opsummeringDA":{"card":{"titel":"RE-TENDER - Centre for Coastal Nature and Sport Fishing, Assens Harbour (dissemination)","ordregiver":"Assens Municipality","ordregiverId":"29189692","ordregiverIdDatavasket":"29189692","publiceringsdato":"2025-05-20+02:00","cpvKode":"45000000","cpvTitel":"Bygge- og anlægsarbejder","formulartype":"Resultater","formulartypeKode":"result","tidsfrister":[],"alleOrdregivere":["Assens Municipality"],"anslaaetVaerdi":"15500000","anslaaetVaerdiValuta":"DKK","beskrivelse":"The present re-tender deals with concept proposals for exhibition and experience design at the National Centre for Coastal Nature and Sport Fishing at the Middle Pier at Assens Harbour. The project is tendered as a turnkey contract.\nThe Centre for Coastal Nature and Sport Fishing will be an experience centre which, through experiences and stories about the sea, coasts, lakes, streams, fish and angling, will make visitors marvel at life beneath the water's surface, and which will make visitors want to try their hand at unique nature experiences.\nWe are looking for a turnkey contractor who can deliver a strong and inspiring concept, thereby creating an attraction of international class.\nA concluded design competition has defined the building framework for the centre, which will have a beautiful location in the transition between the market town (Assens), the coast (the Little Belt) and the coastal landscapes (the Funen archipelago). The centre is expected to open spring 2027.\nReference is also made to the tender documents, which comprise a detailed description of the project.","bkSubTypeKode":"29","bkSubType":"Bekendtgørelse om indgåede kontrakter – det generelle direktiv, standardordningen","erAendring":false},"indholdsType":"HENTET_FRA_TED","sekundaereOrdregivere":[],"udforelsesstedNutsCode":["DK031"],"udforelsesstedSubLand":["Fyn"],"udforelsesstedLand":["Danmark"],"udforelsesstedBy":["Assens"],"tilbudsfrister":[],"intressentfrister":[],"deltagelsefrister":[],"svarfrister":[],"antalParts":0,"antalLots":1,"udbudsDokumenter":[]},"opsummeringEN":{"card":{"titel":"RE-TENDER - Centre for Coastal Nature and Sport Fishing, Assens Harbour (dissemination)","ordregiver":"Assens Municipality","ordregiverId":"29189692","ordregiverIdDatavasket":"29189692","publiceringsdato":"2025-05-20+02:00","cpvKode":"45000000","cpvTitel":"Construction work","formulartype":"Result","formulartypeKode":"result","tidsfrister":[],"alleOrdregivere":["Assens Municipality"],"anslaaetVaerdi":"15500000","anslaaetVaerdiValuta":"DKK","beskrivelse":"The present re-tender deals with concept proposals for exhibition and experience design at the National Centre for Coastal Nature and Sport Fishing at the Middle Pier at Assens Harbour. The project is tendered as a turnkey contract.\nThe Centre for Coastal Nature and Sport Fishing will be an experience centre which, through experiences and stories about the sea, coasts, lakes, streams, fish and angling, will make visitors marvel at life beneath the water's surface, and which will make visitors want to try their hand at unique nature experiences.\nWe are looking for a turnkey contractor who can deliver a strong and inspiring concept, thereby creating an attraction of international class.\nA concluded design competition has defined the building framework for the centre, which will have a beautiful location in the transition between the market town (Assens), the coast (the Little Belt) and the coastal landscapes (the Funen archipelago). The centre is expected to open spring 2027.\nReference is also made to the tender documents, which comprise a detailed description of the project.","bkSubTypeKode":"29","bkSubType":"Contract award notice – general directive, standard regime","erAendring":false},"indholdsType":"HENTET_FRA_TED","sekundaereOrdregivere":[],"udforelsesstedNutsCode":["DK031"],"udforelsesstedSubLand":["Fyn"],"udforelsesstedLand":["Denmark"],"udforelsesstedBy":["Assens"],"tilbudsfrister":[],"intressentfrister":[],"deltagelsefrister":[],"svarfrister":[],"antalParts":0,"antalLots":1,"udbudsDokumenter":[]}}