{"bekendtgoerelseNoegle":{"noticeId":{"value":"16e54f80-aedc-4ec2-9421-bf3e8928ba28"},"noticeVersion":{"value":"01"},"noticePublicationNumber":{"value":"00405713-2026"}},"htmlDA":"\n\n \n 1 Køber1.1 KøberOfficielt navn: Energinet Eltransmission A/S\n Køberens retlige status: Offentlig virksomhed\n Den ordregivende enheds aktiviteter: Elektricitetsrelaterede aktiviteter\n \n \n 2 Procedure2.1 ProcedureTitel: Installation of pipes with horizontal directional drilling (HDD) under Guldborgsund\n and Roskilde Fjord - 23/03722\n Beskrivelse: The Contracting Authority wants to purchase horizontal directional drilling activities\n including installation of PE-pipes for establishing two sets of cable crossings for\n new 145 kV cable sys-tems and fiber connections across Guldborgsund (two pipe sets,\n two cable systems, LOT 1) and Roskilde Fjord (one pipe set, one cable system, LOT\n 2).
The underground power cables will be installed by another Contractor\n by means of Watucab by utilizing the smaller pipes inside a bigger pipe. The Fibre\n Optical Cables (FOC) will be installed in dedicated pipes for this purpose. This tender\n concerns all pipes involved – both the smaller pipes and the bigger pipe on the outside.\n
For further details regarding the purchase, reference is made to the tender\n documents.
The value of the contracts is expected to amount to total 147\n Mio. DKK
The tender is divided into the following lots:
Lot 1:
Cable\n crossings for new 145 kV cable systems and fiber connections across Guldborgsund.\n Two pipe sets, two power cable systems
oPipe #1 from Falster to Lolland.\n Estimated length 1,254 m
oPipe #2 from Falster to Lolland. Estimated length\n 1,207 m
Lot 2: Cable crossings for new 145 kV cable systems and fiber connections\n across
Roskilde Fjord: One pipe set, one power cable system
oPipe\n #1 from Roskilde Fjord West – East landings. Estimated length 1,755 m
Tenders\n can be submitted for one or all partial agreements\n Identifikator for proceduren: a86d3fe7-db2e-4ab6-ba6d-545ed8de5c2e\n \n Udbudsprocedure: Udbud med forhandling/indkaldelse af tilbud med forudgående offentliggørelse\n Proceduren er en hasteprocedure: nej\n 2.1.1 FormålKontraktens hovedformål: Bygge- og anlægsarbejder\n Primær klassifikation (cpv): 45120000 Prøve- og udboring\n Supplerende klassifikation (cpv): 45262422 Arbejde i forbindelse med undersøisk boring\n Supplerende klassifikation (cpv): 45231600 Arbejder i forbindelse med kommunikationsledninger\n Supplerende klassifikation (cpv): 45314300 Kabelinfrastruktur\n \n 2.1.2 Udførelsessted\n Hvor som helst i det pågældende land\n Yderligere oplysninger: Roskilde Fjord: Denmark - Sjælland
Guldborgsund: Denmark - Lolland/Falster\n \n 2.1.3 VærdiAnslået værdi eksklusiv moms: 147.000.000 Dansk krone\n \n 2.1.4 Generelle oplysningerYderligere oplysninger: It should be noted that this is a negotiated procedure. With the exception of basic\n elements, changes may be made to tender documents and their contents as a consequence\n as part of the negotiation process. The tenderer's legal form is not required.
The\n tenders submitted must be valid for a period of 6 months from the specified time limit\n for the submission of tenders. If the tenderer during the negotiation phase, prepares\n and submits revised tenders, such tenders must also be valid for the period of 6 months\n from the specified time limit for these revised tenders
If you wish to apply\n to participate in this tender process, the corresponding ESPD must be filled in. The\n ESPD for this tender process can be found in Comdia.
The ESPD must be filled\n in in Comdia, after which it is submitted via \"Save and Send\". Guidelines for completing\n the ESPD can be found on the website of the Konkurrence- og Forbrugerstyrelsen, www.kfst.dk\n (The contracting entity does not take responsibility for the content of the guidance).\n
Please note the following: - An applicant who participates alone, but relies\n on the capacity of one or more other entities (e.g. a parent company or sister company\n or subcontractor) shall ensure that the application is accompanied by both the applicant's\n own ESPD and a separate ESPD for each entity on which it wishes to rely, with a completed\n Part II \"Information on the economic operator\" and Part III \"Grounds for exclusion\"\n as well as relevant information concern-ing Part IV \"Selection criteria\" and Part\n V: \"Limiting the number of qualified applicants\".
The attached ESPD from\n those other entities should be duly completed and signed.
In addition, the\n submission of final evidence must also be accompanied by evidence of the commitment\n of these entities/subcontractors in this respect in the form of a statement of support.\n - Where groups of economic operators, including temporary associations, apply together,\n a full ESPD shall be filled in separately for each participating economic operator\n containing the required information.
The final documentation must also be\n accompanied by a Consortium Declaration, by which the parties declare to be a consortium\n or other form of association jointly and severally, unconditionally, and directly\n liable for the fulfilment of the contract tendered.
\n \n \n \n 2.1.5 TilbudsvilkårVilkår for indgivelse:Det højeste antal delkontrakter, for hvilket en tilbudsgiver kan indgive tilbud: 2\n \n Betingelser for kontraktens udførelse:Det højeste antal delkontrakter, for hvilket der kan tildeles kontrakter til én tilbudsgiver: 2\n \n \n 2.1.6 UdelukkelsesgrundeKilder til grundlag for udelukkelse: Bekendtgørelse\n Alvorlige forsømmelser i forbindelse med udøvelsen af erhvervet: Is the economic operator guilty of grave professional misconduct? Where applicable,\n see definitions in national law, the relevant
notice or the procurement documents.\n Interessekonflikt som følge af deltagelse i udbudsproceduren: Is the economic operator aware of any conflict of interest, as indicated in national\n law, the relevant notice or the procurement documents due to its participation in\n the procurement procedure?\n Direkte eller indirekte involvering i forberedelsen af denne udbudsprocedure: Has the economic operator or an undertaking related to it advised the contracting\n authority or contracting entity or otherwise been involved in the preparation of the\n procurement procedure?\n Afgivelse af urigtige oplysninger, tilbageholdelse af oplysninger, ude af stand til at fremlægge de dokumenter, der anmodes om, eller indhentede fortrolige oplysninger i forbindelse med denne procedure: Can the economic operator confirm that:
a) It has been guilty of serious misrepresentation\n in supplying the information required for the verification of the absence of grounds\n for exclusion or the fulfilment of the selection criteria,
b) It has withheld\n such information,
c) It has not been able, without delay, to submit the supporting\n documents required by a contracting authority or contracting entity, and
d) It\n has undertaken to unduly influence the decision making process of the contracting\n authority or contracting entity, to obtain confidential information that may confer\n upon it undue advantages in the procurement procedure or to negligently provide misleading\n information that may have a material influence on decisions concerning exclusion,\n selection or award?\n Rent nationale udelukkelsesgrunde: § 134 a. A contracting entity shall exclude a candidate or tenderer from participation\n in a procurement procedure if the candidate or tenderer is established in a country\n that is included on the EU list of non-cooperative jurisdictions for tax purposes\n and has not acceded to the WTO's Government Procurement Agreement or other trade agreements\n obliging Denmark to open the public procurement market to tenderers established in\n that country.\n Terrorhandlinger eller strafbare handlinger med forbindelse til terroraktivitet: Has the economic operator itself or any person who is a member of its administrative,\n management or supervisory body or has powers of representation, decision or control\n therein been the subject of a conviction by final judgment for terrorist offences\n or offences linked to terrorist activities, by a conviction rendered at the most five\n years ago or in which an exclusion period set out directly in the conviction continues\n to be applicable? As defined in Articles 1 and 3 of Council Framework Decision of\n 13 June 2002 on combating terrorism (OJ L 164, 22.6.2002, p. 3). This exclusion ground\n also includes inciting or aiding or abetting or attempting to commit an offence, as\n referred to in Article 4 of that Framework Decision.
For Danish applicants/tenderers\n the documentation is entailed in the “Serviceattest” which can be acquired from the\n Danish Business Authority. The time frame from request of a Serviceattest until receipt\n is usually two weeks.
For foreign applicants/tenderers it is the experience of\n the Contracting Authority that the time frame for receipt of this documentation varies\n within the individual member states. As a result, The Contracting Authority strongly\n advises foreign applicants/tenderers to obtain this documentation as early as possible.\n Preferably the documentation should be ready and available already in connection with\n the prequalification.
The EU Commission has launched e-CERTIS, a free, on-line\n source of information to help companies and contracting authorities to deal with different\n forms of documentary evidence required when tendering for public contracts. Information\n regarding relevant certificates can be obtained from: https://ec.europa.eu/tools/ecertis/#/search\n Tilsidesættelse af forpligtelser vedrørende betaling af bidrag til sociale sikringsordninger: Has the economic operator breached its obligations relating to the payment social\n security contributions, both in the country in which it is established and in Member\n State of the contracting authority or contracting entity if other than the country\n of establishment?
For Danish applicants/tenderers the documentation is entailed\n in the “Serviceattest” which can be acquired from the Danish Business Authority. The\n time frame from request of a Serviceattest until receipt is usually two weeks.
For\n foreign applicants/tenderers it is the experience of the Contracting Authority that\n the time frame for receipt of this documentation varies within the individual member\n states. As a result, The Contracting Authority strongly advises foreign applicants/tenderers\n to obtain this documentation as early as possible. Preferably the documentation should\n be ready and available already in connection with the prequalification.
The EU\n Commission has launched e-CERTIS, a free, on-line source of information to help companies\n and contracting authorities to deal with different forms of documentary evidence required\n when tendering for public contracts. Information regarding relevant certificates can\n be obtained from: https://ec.europa.eu/tools/ecertis/#/search\n Tilsidesættelse af forpligtelser vedrørende betaling af skatter og afgifter: The contracting entity shall exclude a candidate or tenderer who has unpaid overdue\n debts of DKK 100,000 or more to public authorities relating to taxes, duties or social\n security contributions under Danish law or the law of the country in which the applicant\n or tenderer is established. Documentation: in accordance with sections 152-153 of\n the Danish Public Procurement Act.\n Deltagelse i en kriminel organisation: Has the economic operator itself or any person who is a member of its administrative,\n management or supervisory body or has powers of representation, decision or control\n therein been the subject of a conviction by final judgment for participation in a\n criminal organisation, by a conviction rendered at the most five years ago or in which\n an exclusion period set out directly in the conviction continues to be applicable?\n As defined in Article 2 of Council Framework Decision 2008/841/JHA of 24 October 2008\n on the fight against organised crime (OJ L 300, 11.11.2008, p. 42).
For Danish\n applicants/tenderers the documentation is entailed in the “Serviceattest” which can\n be acquired from the Danish Business Authority. The time frame from request of a Serviceattest\n until receipt is usually two weeks.
For foreign applicants/tenderers it is the\n experience of the Contracting Authority that the time frame for receipt of this documentation\n varies within the individual member states. As a result, The Contracting Authority\n strongly advises foreign applicants/tenderers to obtain this documentation as early\n as possible. Preferably the documentation should be ready and available already in\n connection with the prequalification.
The EU Commission has launched e-CERTIS,\n a free, on-line source of information to help companies and contracting authorities\n to deal with different forms of documentary evidence required when tendering for public\n contracts. Information regarding relevant certificates can be obtained from:
https://ec.europa.eu/tools/ecertis/#/search\n Hvidvaskning af penge eller finansiering af terrorisme: Has the economic operator itself or any person who is a member of its administrative,\n management or supervisory body or has powers of representation, decision or control\n therein been the subject of a conviction by final judgment for money laundering or\n terrorist financing, by a conviction rendered at the most five years ago or in which\n an exclusion period set out directly in the conviction continues to be applicable?\n As defined in Article 1 of Directive 2005/60/EC of the European Parliament and of\n the Council of 26 October 2005 on the prevention of the use of the financial system\n for the purpose of money laundering and terrorist financing (OJ L 309, 25.11.2005,\n p. 15).
For Danish applicants/tenderers the documentation is entailed in the “Serviceattest”\n which can be acquired from the Danish Business Authority. The time frame from request\n of a Serviceattest until receipt is usually two weeks.
For foreign applicants/tenderers\n it is the experience of the Contracting Authority that the time frame for receipt\n of this documentation varies within the individual member states. As a result, The\n Contracting Authority strongly advises foreign applicants/tenderers to obtain this\n documentation as early as possible. Preferably the documentation should be ready and\n available already in connection with the prequalification.
The EU Commission\n has launched e-CERTIS, a free, on-line source of information to help companies and\n contracting authorities to deal with different forms of documentary evidence required\n when tendering for public contracts. Information regarding relevant certificates can\n be obtained from: https://ec.europa.eu/tools/ecertis/#/search\n Svig: Has the economic operator itself or any person who is a member of its administrative,\n management or supervisory body or has powers of representation, decision or control\n therein been the subject of a conviction by final judgment for fraud, by a conviction\n rendered at the most five years ago or in which an exclusion period set out directly\n in the conviction continues to be applicable? Within the meaning of Article 1 of the\n Convention on the protection of the European Communities' financial interests (OJ\n C 316, 27.11.1995, p. 48).
For Danish applicants/tenderers the documentation is\n entailed in the “Serviceattest” which can be acquired from the Danish Business Authority.\n The time frame from request of a Serviceattest until receipt is usually two weeks.\n For foreign applicants/tenderers it is the experience of the Contracting Authority\n that the time frame for receipt of this documentation varies within the individual\n member states. As a result, The Contracting Authority strongly advises foreign applicants/tenderers\n to obtain this documentation as early as possible. Preferably the documentation should\n be ready and available already in connection with the prequalification. The EU Commission\n has launched e-CERTIS, a free, on-line source of information to help companies and\n contracting authorities to deal with different forms of documentary evidence required\n when tendering for public contracts. Information regarding relevant certificates can\n be obtained from: https://ec.europa.eu/tools/ecertis/#/search\n Børnearbejde og andre former for menneskehandel: Has the economic operator itself or any person who is a member of its administrative,\n management or supervisory body or has powers of representation, decision or control\n therein been the subject of a conviction by final judgment for child labour and other\n forms of trafficking in human beings, by a conviction rendered at the most five years\n ago or in which an exclusion period set out directly in the conviction continues to\n be applicable? As defined in Article 2 of Directive 2011/36/EU of the European Parliament\n and of the Council of 5 April 2011 on preventing and combating trafficking in human\n beings and protecting its victims, and replacing Council Framework Decision 2002/629/JHA\n (OJ L 101, 15.4.2011, p. 1).
For Danish applicants/tenderers the documentation\n is entailed in the “Serviceattest” which can be acquired from the Danish Business\n Authority. The time frame from request of a Serviceattest until receipt is usually\n two weeks.
For foreign applicants/tenderers it is the experience of the Contracting\n Authority that the time frame for receipt of this documentation varies within the\n individual member states. As a result, The Contracting Authority strongly advises\n foreign applicants/tenderers to obtain this documentation as early as possible. Preferably\n the documentation should be ready and available already in connection with the prequalification.\n
The EU Commission has launched e-CERTIS, a free, on-line source of information\n to help companies and contracting authorities to deal with different forms of documentary\n evidence required when tendering for public contracts. Information regarding relevant\n certificates can be obtained from: https://ec.europa.eu/tools/ecertis/#/search\n Korruption: Has the economic operator itself or any person who is a member of its administrative,\n management or supervisory body or has powers of representation, decision or control\n therein been the subject of a conviction by final judgment for corruption, by a conviction\n rendered at the most five years ago or in which an exclusion period set out directly\n in the conviction continues to be applicable? As defined in Article 3 of the Convention\n on the fight against corruption involving officials of the European Communities or\n officials of Member States of the European Union, OJ C 195, 25.6.1997, p. 1, and in\n Article 2(1) of Council Framework Decision 2003/568/JHA of 22 July 2003 on combating\n corruption in the private sector (OJ L 192, 31.7.2003, p. 54). This exclusion ground\n also includes corruption as defined in the national law of the contracting authority\n (contracting entity) or the economic operator. \"
For Danish applicants/tenderers\n the documentation is entailed in the “Serviceattest” which can be acquired from the\n Danish Business Authority. The time frame from request of a Serviceattest until receipt\n is usually two weeks. For foreign applicants/tenderers it is the experience of the\n Contracting Authority that the time frame for receipt of this documentation varies\n within the individual member states. As a result, The Contracting Authority strongly\n advises foreign applicants/tenderers to obtain this documentation as early as possible.\n Preferably the documentation should be ready and available already in connection with\n the prequalification. The EU Commission has launched e-CERTIS, a free, on-line source\n of information to help companies and contracting authorities to deal with different\n forms of documentary evidence required when tendering for public contracts. Information\n regarding relevant certificates can be obtained from: https://ec.europa.eu/tools/ecertis/#/search\n \n \n \n 5 Delkontrakt5.1 Delkontrakt: LOT-0001Titel: Lot 1 - Cable crossings for new 145 kV cable systems and fiber connections across\n Guldborgsund\n Beskrivelse: Two pipe sets, two power cable systems
oPipe #1 from Falster to Lolland.\n Estimated length 1,254 m
oPipe #2 from Falster to Lolland. Estimated length\n 1,207 m\n \n 5.1.1 FormålKontraktens hovedformål: Bygge- og anlægsarbejder\n Primær klassifikation (cpv): 45120000 Prøve- og udboring\n \n \n 5.1.2 Udførelsessted\n Hvor som helst i det pågældende land\n Yderligere oplysninger: Pipe #1 from Falster to Lolland. Estimated length 1254 m
Pipe #2 from Falster\n to Lolland. Estimated length 1207 m
\n \n \n 5.1.4 FornyelseHøjeste antal fornyelser: 0\n \n 5.1.6 Generelle oplysningerReserveret deltagelse: Deltagelse uden forbehold.\n Navnene på og de faglige kvalifikationer for det personale, der skal udføre kontrakten, skal angives: Ikke påkrævet\n Indkøbsprojekt, der ikke finansieres med EU-midler\n Udbuddet er omfattet af aftalen om offentlige udbud (GPA): ja\n \n 5.1.9 UdvælgelseskriterierKilder til udvælgelseskriterier: Bekendtgørelse\n Kriterium: Finansielt forholdBeskrivelse af udvælgelseskriterium: The applicant must confirm the economic ability in the ESPD part IV.B with information\n from the latest annual report regarding the following economic indicators:
1.\n Equity (total equity incl. share capital, reserves, revaluation, retained earning\n etc.)
2. Equity ratio (equity/total assets). This must be stated with two decimals.
If\n the applicant relies on the capacities of other entities or the applicant is a group\n of economic operators the information for the ESPD part IV.B must also be given in\n a separate ESPD from each of these entities. It is the sole responsibility of the\n applicant to secure that the minimum requirements are reached based on consolidation\n when the applicant is relying on the capacity of other entities or when the applicant\n is a group of economic operators.
Minimum requirement:
LOT 1:
•\n Equity from the latest annual report must, at the time limit for receipt of tenders,\n be at least 28 mill. DKK/3,753 mill. EUR
• Equity ratio from the latest annual\n report must, at the time of prequalification, be at least 20 pct. If the equity ratio\n is between 15 pct. and 20 pct. the tenderer can qualify if Equity exceeds 85,75 mill.\n DKK/ 11,494 mill. EUR\n Kriteriet vil blive anvendt til at udvælge de ansøgere, som skal opfordres til at deltage i anden fase af proceduren\n \n Kriterium: Referencer på specificerede arbejderBeskrivelse af udvælgelseskriterium: The suitability of applicants fulfilling the minimum requirements to economic and\n financial standing will be assessed based on technical and professional ability. The\n ability will be assessed based on references which can be filled in ESPD part IV.C.\n
The applicant is allowed to submit up to 3 most comparable and relevant\n references undertaken in the past 5 years as part of the application. By “com-parable”\n it is understood more than 800 m length of horizontal directional drilling involving\n 100 tons (Thrust/pull-back tension: 1000 kN) or bigger. By \"undertaken in the past\n 5 years” implies that the reference must not have been completed prior to the date\n reached when counting 5 years backwards from the submission date for prequalification.\n Ref-erences older than this will not be taken into consideration. References which\n have not yet been fully completed can be included as part of the application, however\n the applicant must describe the parts which have not yet been delivered, and this\n may affect the evaluation of the application, cf. section 2.3.
The references\n should describe horizontal directional drilling activities, and include:
A\n specific description of deliveries, including:
• Type and scope of HDD works
o\n Length and diameter of pipe installed via HDD
o Description of installed pipe/cable\n and/or casing solution
o Size of drilling rig(s) involved
• Hydro‑geological\n and environmental conditions
o Description of ground conditions encountered (e.g.\n clay, sand, moraine, rock, mixed soils)
o Sensitivity of the surrounding environment\n (e.g. Natura 2000, pro-tected areas, environmental restrictions)
• Quality, HSE\n and documentation
o Applied quality assurance and control measures
o Compliance\n with HSE requirements during drilling under marine waters
o As‑built documentation,\n drilling logs and completion reports
• Contractual role and performance
o\n Contractor’s role (main contractor / subcontractor)
o Time schedule compliance\n and handling of unforeseen ground conditions
o Reference contact details and year\n of completion
• Contact information
o Specification of buying organization,\n contact person and the asso-ciated contact information
Contract value (if\n possible)
Date of initiation and final delivery (day, month, year)
Any\n ambiguities and/or incomprehensibilities may have a negative effect on the selection\n of applicants. Please note the “description” box in ESPD part IV.C. can contain more\n text than is visible and it is possible to copy paste text into the box.
If\n the applicant is relying on the capacity of other entities or the applicant is a group\n of eco-nomic operators the maximum number of references to be submitted must still\n be respected and cannot exceed 3 when combined. If more are submitted, the Contracting\n Authority will only consider the most recent references determined by date of final\n delivery, in this case not yet finished references will not be included.
If\n the applicant relies on other entities capacity or is part of a group of economic\n operators the information concerning ESPD part IV.C must be submitted in separate\n ESPD’s for each entity.
Minimum requirement:
• At least two references\n for horizontal directional drilling of a length of more than 800 meters installing\n Ø500 PE pipes or larger within the last 5 years.
• Listing of drilling rigs of\n 100 tons (Thrust/pull-back tension: 1000 kN) and above that are relevant for the installation\n under tender
• Proven record for work in nature preservation areas like Natura\n 2000, protected areas, environmentally restricted areas or similar.
• Proven\n experience from previous projects with the use of Bentonite products, additives and\n other drilling fluid products for HDD equivalent to the products listed in Appendix\n 2E-1 and Appendix 2E-2.
\n Kriteriet vil blive anvendt til at udvælge de ansøgere, som skal opfordres til at deltage i anden fase af proceduren\n \n Oplysninger om den anden fase i en procedure, der afvikles i to faser:Mindsteantallet af ansøgere, som skal opfordres til at deltage i anden fase af proceduren: 1\n Det højeste antal ansøgere, som skal opfordres til at deltage i anden fase af proceduren: 5\n Proceduren afvikles i successive faser. I hver fase kan nogle ansøgere blive udelukket\n \n \n 5.1.10 TildelingskriterierKriterium:\n Beskrivelse: Price
Prices must be stated in the attached Schedule of Prices and the defined\n price elements must be completed herein. Prices must be stated exclusive of VAT but\n inclu-sive of all other expenses associated with the purchase.
Prices must\n be stated in EUR.
When evaluating 'Price', the Contracting Authority will\n eval-uate the total cost - Total Tender Price, cf. Schedule of Prices.
\n Kategori for tildelingskriteriet vægt: Vægtning (procentdel, præcis)Tildelingskriterium talværdi: 50\n \n \n Kriterium:\n Beskrivelse: Technical solution
Technical description
The evaluation will be based\n on the submitted technical description, including method statements specifications\n and descriptions which demonstrate the technical level for executing the works specified\n in the tender documents.
The work shall be based on a tender engineering\n ap-proach ensuring that that the proposed drilling setup is robust even if the soil\n characteristics differ from the expected.
The tenderer must include Method\n Statements and engineering reports from the Pre-FEED covering all phas-es of the Works.
Reference\n is made to Technical Requirements (doc. no. 23/03722-1)
The evaluation will\n be based on the degree of detail and the technical level of specifications and the\n level of content in the Method Statement(s).
It will be evaluated positive\n if the tenderer submits detailed descriptions that in content and clarity demonstrate\n fulfil-ment of all technical requirements stated in the tender documents. Further,\n it will be evaluated positive that the approach and chosen solutions underline the\n tenderer’s ability and use of competences to execute the works, es-pecially concerning:
•\n Assessment of technical and environmental risks and proposed mitigations
• Quality\n plan
• Method statements
• Engineering document proving that the proposed\n drilling setup is robust even if the soil characteris-tics differ from the expected\n
• Contingency plans for handling blow-outs
• Specification of specialized\n equipment and drilling rigs and drilling bits, including considerations con-cerning\n redundancy of key equipment
• Specification of materials to be used
• Specification\n of PE pipe configuration
• Specification of the PE pipes proposed.
• Specification\n of drilling mud
• Specification of seals
• State the anticipated amount of\n water for per-forming the drilling
• Preliminary drawings of drilling profile
•\n Specifications of working areas
Specification of onshore spread
\n Kategori for tildelingskriteriet vægt: Vægtning (procentdel, præcis)Tildelingskriterium talværdi: 20\n \n \n Kriterium:\n Beskrivelse: Organization
As the Works is of immense importance for the Client, the tenderer\n must enclose CVs of the key personnel who will be allocated to the Works.
The\n following are considered as key personnel:
• Project manager
• Site staff\n foreman
• HSE responsible
• H&S Coordinator (AMK-B)
• Quality Manager
The\n tenderer is encouraged to highlight only the expertise and experience for each key\n personnel relevant for the position in the respective CVs (e.g. educational back-ground,\n experience within that position, experience with similar assignments etc.).
Further,\n the tenderer should submit an Organization Plan. The Organization Plan should include\n a detailed description of the project specific organizational struc-ture down to site\n staff foreman level which will be allocated to the Works during all phases of the\n Works.
The Organization Plan description should describe:
• The overall\n structure, including hierarchy and procedures for escalation.
• Lines of communication,\n internally and external-ly
• Interfaces towards the Contracting Authority.
•\n How the tenderer will secure coverage of all po-sitions at all time
The Organization\n Plan must be described in detail as well as visualized in a project specific organization\n chart.
The evaluation of key personnel will be based on the degree to which the\n experience and professional qualifications of the individual key personnel is up to\n date, relevant in respect of the performance and position of the specific assignment.\n As such a relevant educational background combined with relevant roles in recent projects\n of similar characteristics will be evaluated positively.
Further, the evaluation\n will focus on to which degree the individual key personnel will be involved in the\n fulfilment of the assignment and how the key personnel complement each other.
The\n evaluation of the Organization Plan will be based on the degree of detail and
•\n On whether the proposed plan is project specific, operational, efficient, robust and\n with clear lines of communication.
• On whether the organization is well-structured\n with coverage for all interfaces taking into consid-eration the complexity of the\n Works
• On the coverage of all positions and possibility to scall in manpower\n during execution in order to ful-fil the project time schedule
An overall\n evaluation will be made of this sub-criterion.
\n Kategori for tildelingskriteriet vægt: Vægtning (procentdel, præcis)Tildelingskriterium talværdi: 10\n \n \n Kriterium:\n Beskrivelse: Time Schedule for the Works
The tenderer should include the Project Time Schedule\n in the tender. The Project Time Schedule must be project specific and include all\n activities executed by the tenderer concerning the Works.
The tenderer should\n as part of the sub-criteria include a detailed and robust time schedule for each lot\n which outlines how the works will be structured through FEED and Detailed Engineering,\n construction and pipe installation phases, and delivery of as-built documentation.\n Delays associated with inspections and verifications shall be made clear, if known.\n The time schedule should contain relevant project milestones including the milestones\n outlined in the tender documents.
Reference is made to the Time Schedule\n for the relevant LOT (LOT 1: 23/03722-34 or LOT 2: 23/03722-35).
The time\n schedule should be included both in the form of a chart (GANTT-diagram) with clarifications\n as needed, in a supporting and elaborate description.
The evaluation of the Time\n Schedule will be based on the
level of detail and robustness/timeliness for all\n phases of the Works.
The evaluation of the detailed Project Time Schedule\n pre-pared by the tenderer and included in the tender will be based on the degree of\n detail and division into sub-tasks to prove for the Employer, that the Contractor\n has the capacity to do the Works in accordance within the time frame specified in\n the Clients Time Schedule(s).
The Contracting Authority will evaluate the\n degree to which the tender demonstrates a well-planned, realistic and ro-bust time\n schedule, which allows sufficient time for potential schedule contingencies, but still\n provides evidence of a high level of security for delivery within the timeframe as\n set out in the Tender Documents.
In this context it will be evaluated positive\n that:
- the description and schedule reflect a realistic, but front-loaded schedule\n for the critical activities
- hazardous activities are not performed concurrently\n in the same location
- the division into sub-sections ensures that the ten-derer\n has the capacity to perform in accordance with the overall project time schedule.\n
the description and schedule reflect the tenderer’s ability to catch-up on delays\n and shows activities to activate
\n Kategori for tildelingskriteriet vægt: Vægtning (procentdel, præcis)Tildelingskriterium talværdi: 10\n \n \n Kriterium:\n Beskrivelse: Contract terms
For the evaluation of the sub-criteria the tenderer is allowed\n to propose deviations to the elements of the contract identified as competitive elements\n in the contract terms.
The contract terms consist of:
• Contract Agreement\n for Guldborgsund, doc.no. 23/03722-15 (lot 1)
• Contract Agreement for Roskilde\n Fjord, doc.no. 23/03722-38 (lot 2)
• Appendix 1 [General Conditions based on AB18],\n doc.no. 23/03722-16 (both lots)
The deviations should be enclosed in the\n clarification list c.f. doc.no. 23/03722-6 and be included in the spreadsheet marked\n “Legal clarification”.
The submitted clarification list should be clearly marked\n “Lot 1” or “Lot 2”.
The proposed deviations should be explicit and with explanation\n as to why they are made. The tendered contract must be performed on the basis of the\n contract terms. The tenderer is allowed to propose explicit and well-explained deviations\n to the following listed competitive elements:
- In the Contract Agreements, doc.no.\n 23/03722-15 (lot 1) and doc.no. 23/03722-38 (lot 2):
• Section 5 [Contract Data]\n In terms of:
Liquidated damages and maximum liquidated damages (Clause 40, subclause\n (2)) under [Clause 40. The contractor’s liability in case of delay]
- In\n Appendix 1 [General Conditions based on AB18], doc.no. 23/03722-16 (both lots):
•\n Clause 12 [Services to be provided by the contractor]
• Clause 26 [Obstacles]
•\n Clause 31. Construction meetings
• Chapter E [Extension of time and delay]
•\n Chapter F [Handover]
• Chapter G [Defects]
• Clause 59 [The client’s right\n to terminate the contract]
Deviations to these elements will be included\n in the evaluation and it is noted that any deviations may lead to a reduction of the\n score depending on the content, clarity, and consequence of the deviation. In this\n regard it is explicitly noted that deviations which are intended to limit liability\n and shift the financial risk in favour of the tenderer will be of particular importance\n in the evaluation.
If the tenderer has no deviations to the contract terms, the\n maximum score of 10 will be awarded.
An overall evaluation for each lot will be\n made of this sub-criterion.
\n Kategori for tildelingskriteriet vægt: Vægtning (procentdel, præcis)Tildelingskriterium talværdi: 10\n \n \n \n 5.1.11 TilbudsdokumenterAdresse på udbudsdokumenterne: https://www.comdia.com/energinet/tenderinformationshow.aspx?Id=716721\n \n 5.1.12 TilbudsvilkårVilkår for indgivelse:Elektronisk indgivelse: Påkrævet\n Indgivelsesadresse: https://www.comdia.com/energinet/tenderinformationshow.aspx?Id=716721\n Sprog, som tilbud og ansøgninger om deltagelse kan indgives på: engelsk, dansk\n Elektronisk katalog: Ikke tilladt\n Alternative tilbud: Ikke tilladt\n Tilbudsgivere kan indgive mere end ét tilbud: Ikke tilladt\n Frist for modtagelse af anmodninger om deltagelse: 10-07-2026 12:00 +02:00\n \n Oplysninger, der kan suppleres efter indgivelsesfristen er udløbet:Køberen kan beslutte, at visse manglende tilbudsrelaterede dokumenter kan indsendes senere.\n Yderligere oplysninger: See Tender Material\n \n Betingelser for kontraktens udførelse:Udførelsen af kontrakten skal ske inden for rammerne af programmer for beskyttet beskæftigelse: Nej\n Vilkår relateret til kontraktens udførelse: See contract template.\n Der kræves en fortrolighedsaftale: nej\n Elektronisk fakturering: Påkrævet\n Der vil blive anvendt elektronisk bestilling: ja\n Der vil blive anvendt elektronisk betaling: ja\n Oplysninger om finansiering og betaling: See the tender materiel.
The tenderer's legal form is not required. If applications\n and tenders are submitted by a consortium, all participants in the consortium must\n be jointly and severally liable for the performance of the contract and a consortium\n member must be appointed with whom a binding agreement can be concluded on behalf\n of the consortium\n \n \n 5.1.15 Teknikker\n Oplysninger om det dynamiske indkøbssystem:Intet dynamisk indkøbssystem\n \n \n 5.1.16 Yderligere oplysninger, mægling og gennemgangOrganisation med ansvar for klager: Danish Complaints Board for Public Procurement\n Oplysninger om klagefrister: According to the Danish Complaints Board for Public Procurement Act etc. (the Act\n can be downloaded at www.retsinformation.dk), the following deadlines for filing a\n complaint apply:
Complaints about not having been selected must be submitted to\n the Danish Complaints Board for Public Procurement within 20 calendar days, cf. Section\n 7(1) of the Act, from the day after sending a notification to the candidates concerned\n about who has been selected, when the notification is accompanied by a statement of\n reasons for the decision in accordance with Section 2(1)(1) of the Act and Section\n 171(2) of the Public Procurement Act.
In other situations, complaints about tenders,\n cf. Section 7(2) of the Act, must be submitted to the Complaints Board for Public\n Procurement within:
1) 45 calendar days after the contracting entity has published\n a notice in the Official Journal of the European Union that it has entered into a\n contract. The deadline is calculated from the day after the date on which the announcement\n has been published.
2) 20 calendar days from the day after the contracting entity\n has announced its decision, cf. Section 185(2) of the Public Procurement Act. No later\n than the same time that a complaint is submitted to the Complaints Board for Public\n Procurement, the complainant must inform the contracting entity in writing that a\n complaint is submitted to the Complaints Board for Public Procurement and whether\n the complaint has been submitted during the standstill period, cf. Section 6(4) of\n the Act. In cases where the complaint has not been submitted during the standstill\n period, the complainant must also state whether the complaint is to be given suspensive\n effect, cf. Section 12(1) of the Act.
The Complaints Board for Public Procurement's\n e-mail address is stated in Section VI.4.1).
The Complaints Board for Public Procurement's\n complaint guide can be found at: www.erhvervsstyrelsen.dk.\n Organisation, der leverer supplerende oplysninger om udbudsproceduren: Energinet Eltransmission A/S\n Organisation, der sikrer adgang til udbudsdokumenterne offline: Energinet Eltransmission A/S\n Organisation, der leverer yderligere oplysninger om klageprocedurerne: Danish Competition and Consumer Authority\n Organisation, der modtager ansøgninger om deltagelse: Energinet Eltransmission A/S\n Organisation, der behandler tilbud: Energinet Eltransmission A/S\n \n \n 5.1 Delkontrakt: LOT-0002Titel: Lot 2 - Cable crossings for new 145 kV cable systems and fiber connections across\n Roskilde Fjord\n Beskrivelse: Roskilde Fjord: One pipe set, one power cable system
oPipe #1 from Roskilde\n Fjord West – East landings. Estimated length 1,755 m
Tenders can be submitted\n for one or all partial agreements\n \n 5.1.1 FormålKontraktens hovedformål: Bygge- og anlægsarbejder\n Primær klassifikation (cpv): 45120000 Prøve- og udboring\n \n \n 5.1.2 Udførelsessted\n Hvor som helst i det pågældende land\n Yderligere oplysninger: Roskilde Fjord: Denmark - Zealand\n \n \n 5.1.4 FornyelseHøjeste antal fornyelser: 0\n \n 5.1.6 Generelle oplysningerReserveret deltagelse: Deltagelse uden forbehold.\n Navnene på og de faglige kvalifikationer for det personale, der skal udføre kontrakten, skal angives: Ikke påkrævet\n Indkøbsprojekt, der ikke finansieres med EU-midler\n Udbuddet er omfattet af aftalen om offentlige udbud (GPA): ja\n \n 5.1.9 UdvælgelseskriterierKilder til udvælgelseskriterier: Bekendtgørelse\n Kriterium: Finansielt forholdBeskrivelse af udvælgelseskriterium: The applicant must confirm the economic ability in the ESPD part IV.B with information\n from the latest annual report regarding the following economic indicators:
1.\n Equity (total equity incl. share capital, reserves, revaluation, retained earning\n etc.)
2. Equity ratio (equity/total assets). This must be stated with two decimals.
If\n the applicant relies on the capacities of other entities or the applicant is a group\n of economic operators the information for the ESPD part IV.B must also be given in\n a separate ESPD from each of these entities. It is the sole responsibility of the\n applicant to secure that the minimum requirements are reached based on consolidation\n when the applicant is relying on the capacity of other entities or when the applicant\n is a group of economic operators.
Minimum requirement:
LOT 2:
•\n Equity from the latest annual report must, at the time limit for receipt of tenders,\n be at least 20 mill. DKK/2,681 mill. EUR
• Equity ratio from the latest annual\n report must, at the time of prequalification, be at least 20 pct. If the equity ratio\n is between 15 pct. and 20 pct. the tenderer can qualify if Equity exceeds 61,25 mill.\n DKK/8,210 mill. EUR\n Kriteriet vil blive anvendt til at udvælge de ansøgere, som skal opfordres til at deltage i anden fase af proceduren\n \n Kriterium: Referencer på specificerede arbejderBeskrivelse af udvælgelseskriterium: The suitability of applicants fulfilling the minimum requirements to economic and\n financial standing will be assessed based on technical and professional ability. The\n ability will be assessed based on references which can be filled in ESPD part IV.C.\n
The applicant is allowed to submit up to 3 most comparable and relevant\n references undertaken in the past 5 years as part of the application. By “com-parable”\n it is understood more than 800 m length of horizontal directional drilling involving\n 100 tons (Thrust/pull-back tension: 1000 kN) or bigger. By \"undertaken in the past\n 5 years” implies that the reference must not have been completed prior to the date\n reached when counting 5 years backwards from the submission date for prequalification.\n Ref-erences older than this will not be taken into consideration. References which\n have not yet been fully completed can be included as part of the application, however\n the applicant must describe the parts which have not yet been delivered, and this\n may affect the evaluation of the application, cf. section 2.3.
The references\n should describe horizontal directional drilling activities, and include:
A\n specific description of deliveries, including:
• Type and scope of HDD works
o\n Length and diameter of pipe installed via HDD
o Description of installed pipe/cable\n and/or casing solution
o Size of drilling rig(s) involved
• Hydro‑geological\n and environmental conditions
o Description of ground conditions encountered (e.g.\n clay, sand, mo-raine, rock, mixed soils)
o Sensitivity of the surrounding environment\n (e.g. Natura 2000, pro-tected areas, environmental restrictions)
• Quality, HSE\n and documentation
o Applied quality assurance and control measures
o Compliance\n with HSE requirements during drilling under marine waters
o As‑built documentation,\n drilling logs and completion reports
• Contractual role and performance
o\n Contractor’s role (main contractor / subcontractor)
o Time schedule compliance\n and handling of unforeseen ground conditions
o Reference contact details and year\n of completion
• Contact information
o Specification of buying organization,\n contact person and the asso-ciated contact information
Contract value (if\n possible)
Date of initiation and final delivery (day, month, year)
Any\n ambiguities and/or incomprehensibilities may have a negative effect on the selection\n of applicants. Please note the “description” box in ESPD part IV.C. can contain more\n text than is visible and it is possible to copy paste text into the box.
If\n the applicant is relying on the capacity of other entities or the applicant is a group\n of eco-nomic operators the maximum number of references to be submitted must still\n be respected and cannot exceed 3 when combined. If more are submitted, the Contracting\n Authority will only consider the most recent references determined by date of final\n delivery, in this case not yet finished references will not be included.
If\n the applicant relies on other entities capacity or is part of a group of economic\n operators the information concerning ESPD part IV.C must be submitted in separate\n ESPD’s for each entity.
Minimum requirement:
• At least two references\n for horizontal directional drilling of a length of more than 800 meters installing\n Ø500 PE pipes or larger within the last 5 years.
• Listing of drilling rigs of\n 100 tons (Thrust/pull-back tension: 1000 kN) and above that are relevant for the installation\n under tender
• Proven record for work in nature preservation areas like Natura\n 2000, protected are-as, environmentally restricted areas or similar.
• Proven\n experience from previous projects with the use of Bentonite products, addi-tives and\n other drilling fluid products for HDD equivalent to the products listed in Ap-pendix\n 2E-1 and Appendix 2E-2.
\n Kriteriet vil blive anvendt til at udvælge de ansøgere, som skal opfordres til at deltage i anden fase af proceduren\n \n Oplysninger om den anden fase i en procedure, der afvikles i to faser:Mindsteantallet af ansøgere, som skal opfordres til at deltage i anden fase af proceduren: 1\n Det højeste antal ansøgere, som skal opfordres til at deltage i anden fase af proceduren: 5\n Proceduren afvikles i successive faser. I hver fase kan nogle ansøgere blive udelukket\n \n \n 5.1.10 TildelingskriterierKriterium:\n Beskrivelse: Price
Prices must be stated in the attached Schedule of Prices and the defined\n price elements must be completed herein. Prices must be stated exclusive of VAT but\n inclu-sive of all other expenses associated with the purchase.
Prices must\n be stated in EUR.
When evaluating 'Price', the Contracting Authority will\n eval-uate the total cost - Total Tender Price, cf. Schedule of Prices.
\n Kategori for tildelingskriteriet vægt: Vægtning (procentdel, præcis)Tildelingskriterium talværdi: 50\n \n \n Kriterium:\n Beskrivelse: Technical solution
The evaluation will be based on the submitted technical description,\n including method statements specifications and descriptions which demonstrate the\n technical level for executing the works specified in the tender docu-ments.
The\n work shall be based on a tender engineering ap-proach ensuring that that the proposed\n drilling setup is robust even if the soil characteristics differ from the expected.\n
The tenderer must include Method Statements and engineering reports from\n the Pre-FEED covering all phas-es of the Works.
Reference is made to Technical\n Requirements (doc. no. 23/03722-1)
The evaluation will be based on the degree\n of detail and the technical level of specifications and the level of content in the\n Method Statement(s).
It will be evaluated positive if the tenderer submits\n detailed descriptions that in content and clarity demonstrate fulfil-ment of all technical\n requirements stated in the tender documents. Further, it will be evaluated positive\n that the approach and chosen solutions underline the tenderer’s ability and use of\n competences to execute the works, es-pecially concerning:
• Assessment of technical\n and environmental risks and proposed mitigations
• Quality plan
• Method statements\n
• Engineering document proving that the proposed drilling setup is robust even\n if the soil characteris-tics differ from the expected
• Contingency plans for\n handling blow-outs
• Specification of specialized equipment and drilling rigs\n and drilling bits, including considerations con-cerning redundancy of key equipment
•\n Specification of materials to be used
• Specification of PE pipe configuration\n
• Specification of the PE pipes proposed.
• Specification of drilling mud
•\n Specification of seals
• State the anticipated amount of water for per-forming\n the drilling
• Preliminary drawings of drilling profile
• Specifications of\n working areas
Specification of onshore spread
\n Kategori for tildelingskriteriet vægt: Vægtning (procentdel, præcis)Tildelingskriterium talværdi: 20\n \n \n Kriterium:\n Beskrivelse: Organization
As the Works is of immense importance for the Client , the tenderer\n must enclose CVs of the key personnel who will be allocated to the Works.
The\n following are considered as key personnel:
• Project manager
• Site staff\n foreman
• HSE responsible
• H&S Coordinator (AMK-B)
• Quality Manager
The\n tenderer is encouraged to highlight only the expertise and experience for each key\n personnel relevant for the position in the respective CVs (e.g. educational back-ground,\n experience within that position, experience with similar assignments etc.).
Further,\n the tenderer should submit an Organization Plan. The Organization Plan should include\n a detailed description of the project specific organizational structure down to site\n staff foreman level which will be allocated to the Works during all phases of the\n Works.
The Organization Plan description should describe:
• The overall\n structure, including hierarchy and procedures for escalation.
• Lines of communication,\n internally and external-ly
• Interfaces towards the Contracting Authority.
•\n How the tenderer will secure coverage of all po-sitions at all time
The Organization\n Plan must be described in detail as well as visualized in a project specific organization\n chart.
The evaluation of key personnel will be based on the degree to which the\n experience and professional qualifications of the individual key personnel is up to\n date, relevant in respect of the performance and position of the specific assignment.\n As such a relevant educational background combined with relevant roles in recent projects\n of similar char-acteristics will be evaluated positively.
Further, the evaluation\n will focus on to which degree the individual key personnel will be involved in the\n fulfilment of the assignment and how the key personnel complement each other.
The\n evaluation of the Organization Plan will be based on the degree of detail and
•\n On whether the proposed plan is project specific, operational, efficient, robust and\n with clear lines of communication.
• On whether the organization is well-structured\n with coverage for all interfaces taking into consideration the complexity of the Works
•\n On the coverage of all positions and possibility to scall in manpower during execution\n in order to fulfil the project time schedule
An overall evaluation will\n be made of this sub-criterion
\n Kategori for tildelingskriteriet vægt: Vægtning (procentdel, præcis)Tildelingskriterium talværdi: 10\n \n \n Kriterium:\n Beskrivelse: Time Schedule for the Works
The tenderer should include the Project Time Schedule\n in the tender. The Project Time Schedule must be project specific and include all\n activities executed by the tenderer concerning the Works.
The tenderer should\n as part of the sub-criteria include a detailed and robust time schedule for each lot\n which outlines how the works will be structured through FEED and Detailed Engineering,\n construction and pipe installation phases, and delivery of as-built documentation.\n Delays associated with inspections and verifications shall be made clear, if known.\n The time schedule should contain relevant project milestones including the milestones\n outlined in the tender documents.
Reference is made to the Time Schedule\n for the relevant LOT (LOT 1: 23/03722-34 or LOT 2: 23/03722-35).
The time\n schedule should be included both in the form of a chart (GANTT-diagram) with clarifications\n as needed, in a supporting and elaborate description.
The evaluation of\n the Time Schedule will be based on the
level of detail and robustness/timeliness\n for all phases of the Works.
The evaluation of the detailed Project Time\n Schedule prepared by the tenderer and included in the tender will be based on the\n degree of detail and division into sub-tasks to prove for the Employer, that the Contractor\n has the capacity to do the Works in accordance within the time frame specified in\n the Clients Time Schedule(s).
The Contracting Authority will evaluate the\n degree to which the tender demonstrates a well-planned, realistic and robust time\n schedule, which allows sufficient time for potential schedule contingencies, but still\n provides evidence of a high level of security for delivery within the timeframe as\n set out in the Tender Documents.
In this context it will be evaluated positive\n that:
- the description and schedule reflect a realistic, but front-loaded schedule\n for the critical activities
- hazardous activities are not performed concurrently\n in the same location
- the division into sub-sections ensures that the tenderer\n has the capacity to perform in accordance with the overall project time schedule.\n
the description and schedule reflect the tenderer’s ability to catch-up on delays\n and shows activities to activate
\n Kategori for tildelingskriteriet vægt: Vægtning (procentdel, præcis)Tildelingskriterium talværdi: 10\n \n \n Kriterium:\n Beskrivelse: Contract terms
For the evaluation of the sub-criteria the tenderer is allowed\n to propose deviations to the elements of the contract identified as competitive elements\n in the contract terms.
The contract terms consist of:
• Contract Agreement\n for Guldborgsund, doc.no. 23/03722-15 (lot 1)
• Contract Agreement for Roskilde\n Fjord, doc.no. 23/03722-38 (lot 2)
• Appendix 1 [General Conditions based on AB18],\n doc.no. 23/03722-16 (both lots)
The deviations should be enclosed in the\n clarification list c.f. doc.no. 23/03722-6 and be included in the spreadsheet marked\n “Legal clarification”.
The submitted clarification list should be clearly marked\n “Lot 1” or “Lot 2”.
The proposed deviations should be explicit and with explanation\n as to why they are made. The tendered contract must be performed on the basis of the\n contract terms. The tenderer is allowed to propose explicit and well-explained deviations\n to the following listed competitive elements:
- In the Contract Agreements, doc.no.\n 23/03722-15 (lot 1) and doc.no. 23/03722-38 (lot 2):
• Section 5 [Contract Data]\n In terms of:
Liquidated damages and maximum liquidated damages (Clause 40, subclause\n (2)) under [Clause 40. The contractor’s liability in case of delay]
- In\n Appendix 1 [General Conditions based on AB18], doc.no. 23/03722-16 (both lots):
•\n Clause 12 [Services to be provided by the contractor]
• Clause 26 [Obstacles]
•\n Clause 31. Construction meetings
• Chapter E [Extension of time and delay]
•\n Chapter F [Handover]
• Chapter G [Defects]
• Clause 59 [The client’s right\n to terminate the contract]
Deviations to these elements will be included\n in the evaluation and it is noted that any deviations may lead to a reduction of the\n score depending on the content, clarity, and consequence of the deviation. In this\n regard it is explicitly noted that deviations which are intended to limit liability\n and shift the financial risk in favour of the tenderer will be of particular importance\n in the evaluation.
If the tenderer has no deviations to the contract terms, the\n maximum score of 10 will be awarded.
An overall evaluation for each lot will be\n made of this sub-criterion.
\n Kategori for tildelingskriteriet vægt: Vægtning (procentdel, præcis)Tildelingskriterium talværdi: 10\n \n \n \n 5.1.11 TilbudsdokumenterAdresse på udbudsdokumenterne: https://www.comdia.com/energinet/tenderinformationshow.aspx?Id=716721\n \n 5.1.12 TilbudsvilkårVilkår for indgivelse:Elektronisk indgivelse: Påkrævet\n Indgivelsesadresse: https://www.comdia.com/energinet/tenderinformationshow.aspx?Id=716721\n Sprog, som tilbud og ansøgninger om deltagelse kan indgives på: engelsk, dansk\n Elektronisk katalog: Ikke tilladt\n Frist for modtagelse af anmodninger om deltagelse: 10-07-2026 12:00 +02:00\n \n Oplysninger, der kan suppleres efter indgivelsesfristen er udløbet:Køberen kan beslutte, at visse manglende tilbudsrelaterede dokumenter kan indsendes senere.\n Yderligere oplysninger: See Tender Material\n \n Betingelser for kontraktens udførelse:Udførelsen af kontrakten skal ske inden for rammerne af programmer for beskyttet beskæftigelse: Nej\n Vilkår relateret til kontraktens udførelse: See contract template.\n Der kræves en fortrolighedsaftale: nej\n Elektronisk fakturering: Påkrævet\n Der vil blive anvendt elektronisk bestilling: ja\n Der vil blive anvendt elektronisk betaling: ja\n Oplysninger om finansiering og betaling: See the tender materiel.
The tenderer's legal form is not required. If applications\n and tenders are submitted by a consortium, all participants in the consortium must\n be jointly and severally liable for the performance of the con-tract and a consortium\n member must be appointed with whom a binding agreement can be concluded on behalf\n of the consortium\n \n \n 5.1.15 Teknikker\n Oplysninger om det dynamiske indkøbssystem:Intet dynamisk indkøbssystem\n \n \n 5.1.16 Yderligere oplysninger, mægling og gennemgangOrganisation med ansvar for klager: Danish Complaints Board for Public Procurement\n Oplysninger om klagefrister: According to the Danish Complaints Board for Public Procurement Act etc. (the Act\n can be downloaded at www.retsinformation.dk), the following deadlines for filing a\n complaint apply:
Complaints about not having been selected must be submitted to\n the Danish Complaints Board for Public Procurement within 20 calendar days, cf. Section\n 7(1) of the Act, from the day after sending a notification to the candidates concerned\n about who has been selected, when the notification is accompanied by a statement of\n reasons for the decision in accordance with Section 2(1)(1) of the Act and Section\n 171(2) of the Public Procurement Act.
In other situations, complaints about tenders,\n cf. Section 7(2) of the Act, must be submitted to the Complaints Board for Public\n Procurement within:
1) 45 calendar days after the contracting entity has published\n a notice in the Official Journal of the European Union that it has entered into a\n contract. The deadline is calculated from the day after the date on which the announcement\n has been published.
2) 20 calendar days from the day after the contracting entity\n has announced its decision, cf. Section 185(2) of the Public Procurement Act. No later\n than the same time that a complaint is submitted to the Complaints Board for Public\n Procurement, the complainant must inform the contracting entity in writing that a\n complaint is submitted to the Complaints Board for Public Procurement and whether\n the complaint has been submitted during the standstill period, cf. Section 6(4) of\n the Act. In cases where the complaint has not been submitted during the standstill\n period, the complainant must also state whether the complaint is to be given suspensive\n effect, cf. Section 12(1) of the Act.
The Complaints Board for Public Procurement's\n e-mail address is stated in Section VI.4.1).
The Complaints Board for Public Procurement's\n complaint guide can be found at: www.erhvervsstyrelsen.dk.\n Organisation, der leverer supplerende oplysninger om udbudsproceduren: Energinet Eltransmission A/S\n Organisation, der sikrer adgang til udbudsdokumenterne offline: Energinet Eltransmission A/S\n Organisation, der leverer yderligere oplysninger om klageprocedurerne: Danish Competition and Consumer Authority\n Organisation, der modtager ansøgninger om deltagelse: Energinet Eltransmission A/S\n Organisation, der behandler tilbud: Energinet Eltransmission A/S\n \n \n \n 8 Organisationer8.1 ORG-0001Officielt navn: Energinet Eltransmission A/S\n Registreringsnummer: 39314878\n Postadresse: Tonne Kjærsvej 65 \n \n \n Landsdel (NUTS): Sydjylland (DK032)\n \n \n E-mail: procurement@energinet.dk\n \n Internetadresse: https://energinet.dk/\n Denne organisations roller:\n Organisation, der leverer supplerende oplysninger om udbudsproceduren\n Organisation, der sikrer adgang til udbudsdokumenterne offline\n Organisation, der modtager ansøgninger om deltagelse\n Organisation, der behandler tilbud\n \n \n 8.1 ORG-1000Officielt navn: Comdia ApS\n Registreringsnummer: 33501404\n Postadresse: Lindvedvej 71 \n \n \n Landsdel (NUTS): Fyn (DK031)\n \n E-mail: support@comdia.com\n \n Internetadresse: https://www.comdia.com/\n Denne organisations roller:\n \n \n 8.1 ORG-1001Officielt navn: Danish Complaints Board for Public Procurement\n Registreringsnummer: 37795526\n Postadresse: Danish Appeals Boards Authority, Toldboden 2 \n \n \n Landsdel (NUTS): Vestjylland (DK041)\n \n E-mail: klfu@naevneneshus.dk\n \n Internetadresse: http://www.klfu.dk\n Denne organisations roller:Organisation med ansvar for klager\n \n \n 8.1 ORG-1002Officielt navn: Danish Competition and Consumer Authority\n Registreringsnummer: 10294819\n Postadresse: Carl Jacobsens Vej 35 \n \n \n Landsdel (NUTS): Københavns omegn (DK012)\n \n \n \n Internetadresse: https://www.kfst.dk/\n Denne organisations roller:Organisation, der leverer yderligere oplysninger om klageprocedurerne\n \n \n \n 10 ÆndringUdgave af den foregående bekendtgørelse, der skal ændres: 335420-2026\n Hovedårsagen til ændringen: Berigtigelse – køber\n Beskrivelse: Energinet has decided to extend the period of validity for references from 5 to 10\n years. The change has been made to ensure a sufficiently broad and competitive pool\n of applicants, without compromising the requirements regarding the applicants’ relevant\n experience. The validity of references has been changed in the tender conditions as\n well as in the ESPD. The extension of the period of validity for references from 5\n to 10 years applies for both LOTS (LOT 1 and LOT 2)
Furthermore, Energinet\n has decided to accept references concerning the installation of steel pipes as equivalent\n to references concerning horizontal directional drilling involving the installation\n of PE pipes. Section 2.2.2 concerning the minimum requirements has been amended accordingly.
Due\n to the above changes regarding the validity of references, deadline for submission\n of prequalification has been extended. The new date for submission of prequalification\n is 10 July 2026, at 12:00 (noon)Danish local time.
\n \n Oplysninger om bekendtgørelsenBekendtgørelsens ID: 16e54f80-aedc-4ec2-9421-bf3e8928ba28 - 01\n Formulartype: Konkurrencevilkår\n Bekendtgørelsestype: Udbuds- eller koncessionsbekendtgørelse – standardordningen\n Afsendelsesdato for bekendtgørelsen: 11-06-2026 14:07 +02:00\n Bekendtgørelsens officielle sprog: engelsk \n Bekendtgørelsesnummer: 00405713-2026\n \n Offentliggørelsesdato: 12-06-2026\n \n \n","htmlEN":"\n\n \n 1 Buyer1.1 BuyerOfficial name: Energinet Eltransmission A/S\n Legal type of the buyer: Public undertaking\n Activity of the contracting entity: Electricity-related activities\n \n \n 2 Procedure2.1 ProcedureTitle: Installation of pipes with horizontal directional drilling (HDD) under Guldborgsund\n and Roskilde Fjord - 23/03722\n Description: The Contracting Authority wants to purchase horizontal directional drilling activities\n including installation of PE-pipes for establishing two sets of cable crossings for\n new 145 kV cable sys-tems and fiber connections across Guldborgsund (two pipe sets,\n two cable systems, LOT 1) and Roskilde Fjord (one pipe set, one cable system, LOT\n 2).
The underground power cables will be installed by another Contractor\n by means of Watucab by utilizing the smaller pipes inside a bigger pipe. The Fibre\n Optical Cables (FOC) will be installed in dedicated pipes for this purpose. This tender\n concerns all pipes involved – both the smaller pipes and the bigger pipe on the outside.\n
For further details regarding the purchase, reference is made to the tender\n documents.
The value of the contracts is expected to amount to total 147\n Mio. DKK
The tender is divided into the following lots:
Lot 1:
Cable\n crossings for new 145 kV cable systems and fiber connections across Guldborgsund.\n Two pipe sets, two power cable systems
oPipe #1 from Falster to Lolland.\n Estimated length 1,254 m
oPipe #2 from Falster to Lolland. Estimated length\n 1,207 m
Lot 2: Cable crossings for new 145 kV cable systems and fiber connections\n across
Roskilde Fjord: One pipe set, one power cable system
oPipe\n #1 from Roskilde Fjord West – East landings. Estimated length 1,755 m
Tenders\n can be submitted for one or all partial agreements\n Procedure identifier: a86d3fe7-db2e-4ab6-ba6d-545ed8de5c2e\n Internal identifier: 716721\n Type of procedure: Negotiated with prior publication of a call for competition / competitive with negotiation\n The procedure is accelerated: no\n 2.1.1 PurposeMain nature of the contract: Works\n Main classification (cpv): 45120000 Test drilling and boring work\n Additional classification (cpv): 45262422 Subsea drilling work\n Additional classification (cpv): 45231600 Construction work for communication lines\n Additional classification (cpv): 45314300 Installation of cable infrastructure\n \n 2.1.2 Place of performance\n Anywhere in the given country\n Additional information: Roskilde Fjord: Denmark - Sjælland
Guldborgsund: Denmark - Lolland/Falster\n \n 2.1.3 ValueEstimated value excluding VAT: 147.000.000 Danish krone\n \n 2.1.4 General informationAdditional information: It should be noted that this is a negotiated procedure. With the exception of basic\n elements, changes may be made to tender documents and their contents as a consequence\n as part of the negotiation process. The tenderer's legal form is not required.
The\n tenders submitted must be valid for a period of 6 months from the specified time limit\n for the submission of tenders. If the tenderer during the negotiation phase, prepares\n and submits revised tenders, such tenders must also be valid for the period of 6 months\n from the specified time limit for these revised tenders
If you wish to apply\n to participate in this tender process, the corresponding ESPD must be filled in. The\n ESPD for this tender process can be found in Comdia.
The ESPD must be filled\n in in Comdia, after which it is submitted via \"Save and Send\". Guidelines for completing\n the ESPD can be found on the website of the Konkurrence- og Forbrugerstyrelsen, www.kfst.dk\n (The contracting entity does not take responsibility for the content of the guidance).\n
Please note the following: - An applicant who participates alone, but relies\n on the capacity of one or more other entities (e.g. a parent company or sister company\n or subcontractor) shall ensure that the application is accompanied by both the applicant's\n own ESPD and a separate ESPD for each entity on which it wishes to rely, with a completed\n Part II \"Information on the economic operator\" and Part III \"Grounds for exclusion\"\n as well as relevant information concern-ing Part IV \"Selection criteria\" and Part\n V: \"Limiting the number of qualified applicants\".
The attached ESPD from\n those other entities should be duly completed and signed.
In addition, the\n submission of final evidence must also be accompanied by evidence of the commitment\n of these entities/subcontractors in this respect in the form of a statement of support.\n - Where groups of economic operators, including temporary associations, apply together,\n a full ESPD shall be filled in separately for each participating economic operator\n containing the required information.
The final documentation must also be\n accompanied by a Consortium Declaration, by which the parties declare to be a consortium\n or other form of association jointly and severally, unconditionally, and directly\n liable for the fulfilment of the contract tendered.
\n \n \n \n 2.1.5 Terms of procurementTerms of submission:Maximum number of lots for which one tenderer can submit tenders: 2\n \n Terms of contract:Maximum number of lots for which contracts can be awarded to one tenderer: 2\n \n \n 2.1.6 Grounds for exclusionSources of grounds for exclusion: Notice\n Grave professional misconduct: Is the economic operator guilty of grave professional misconduct? Where applicable,\n see definitions in national law, the relevant
notice or the procurement documents.\n Conflict of interest due to its participation in the procurement procedure: Is the economic operator aware of any conflict of interest, as indicated in national\n law, the relevant notice or the procurement documents due to its participation in\n the procurement procedure?\n Direct or indirect involvement in the preparation of this procurement procedure: Has the economic operator or an undertaking related to it advised the contracting\n authority or contracting entity or otherwise been involved in the preparation of the\n procurement procedure?\n Misrepresentation, withheld information, unable to provide required documents or obtained confidential information of this procedure: Can the economic operator confirm that:
a) It has been guilty of serious misrepresentation\n in supplying the information required for the verification of the absence of grounds\n for exclusion or the fulfilment of the selection criteria,
b) It has withheld\n such information,
c) It has not been able, without delay, to submit the supporting\n documents required by a contracting authority or contracting entity, and
d) It\n has undertaken to unduly influence the decision making process of the contracting\n authority or contracting entity, to obtain confidential information that may confer\n upon it undue advantages in the procurement procedure or to negligently provide misleading\n information that may have a material influence on decisions concerning exclusion,\n selection or award?\n Purely national exclusion grounds: § 134 a. A contracting entity shall exclude a candidate or tenderer from participation\n in a procurement procedure if the candidate or tenderer is established in a country\n that is included on the EU list of non-cooperative jurisdictions for tax purposes\n and has not acceded to the WTO's Government Procurement Agreement or other trade agreements\n obliging Denmark to open the public procurement market to tenderers established in\n that country.\n Terrorist offences or offences linked to terrorist activities: Has the economic operator itself or any person who is a member of its administrative,\n management or supervisory body or has powers of representation, decision or control\n therein been the subject of a conviction by final judgment for terrorist offences\n or offences linked to terrorist activities, by a conviction rendered at the most five\n years ago or in which an exclusion period set out directly in the conviction continues\n to be applicable? As defined in Articles 1 and 3 of Council Framework Decision of\n 13 June 2002 on combating terrorism (OJ L 164, 22.6.2002, p. 3). This exclusion ground\n also includes inciting or aiding or abetting or attempting to commit an offence, as\n referred to in Article 4 of that Framework Decision.
For Danish applicants/tenderers\n the documentation is entailed in the “Serviceattest” which can be acquired from the\n Danish Business Authority. The time frame from request of a Serviceattest until receipt\n is usually two weeks.
For foreign applicants/tenderers it is the experience of\n the Contracting Authority that the time frame for receipt of this documentation varies\n within the individual member states. As a result, The Contracting Authority strongly\n advises foreign applicants/tenderers to obtain this documentation as early as possible.\n Preferably the documentation should be ready and available already in connection with\n the prequalification.
The EU Commission has launched e-CERTIS, a free, on-line\n source of information to help companies and contracting authorities to deal with different\n forms of documentary evidence required when tendering for public contracts. Information\n regarding relevant certificates can be obtained from: https://ec.europa.eu/tools/ecertis/#/search\n Breaching obligation relating to payment of social security contributions: Has the economic operator breached its obligations relating to the payment social\n security contributions, both in the country in which it is established and in Member\n State of the contracting authority or contracting entity if other than the country\n of establishment?
For Danish applicants/tenderers the documentation is entailed\n in the “Serviceattest” which can be acquired from the Danish Business Authority. The\n time frame from request of a Serviceattest until receipt is usually two weeks.
For\n foreign applicants/tenderers it is the experience of the Contracting Authority that\n the time frame for receipt of this documentation varies within the individual member\n states. As a result, The Contracting Authority strongly advises foreign applicants/tenderers\n to obtain this documentation as early as possible. Preferably the documentation should\n be ready and available already in connection with the prequalification.
The EU\n Commission has launched e-CERTIS, a free, on-line source of information to help companies\n and contracting authorities to deal with different forms of documentary evidence required\n when tendering for public contracts. Information regarding relevant certificates can\n be obtained from: https://ec.europa.eu/tools/ecertis/#/search\n Breaching obligation relating to payment of taxes: The contracting entity shall exclude a candidate or tenderer who has unpaid overdue\n debts of DKK 100,000 or more to public authorities relating to taxes, duties or social\n security contributions under Danish law or the law of the country in which the applicant\n or tenderer is established. Documentation: in accordance with sections 152-153 of\n the Danish Public Procurement Act.\n Participation in a criminal organisation: Has the economic operator itself or any person who is a member of its administrative,\n management or supervisory body or has powers of representation, decision or control\n therein been the subject of a conviction by final judgment for participation in a\n criminal organisation, by a conviction rendered at the most five years ago or in which\n an exclusion period set out directly in the conviction continues to be applicable?\n As defined in Article 2 of Council Framework Decision 2008/841/JHA of 24 October 2008\n on the fight against organised crime (OJ L 300, 11.11.2008, p. 42).
For Danish\n applicants/tenderers the documentation is entailed in the “Serviceattest” which can\n be acquired from the Danish Business Authority. The time frame from request of a Serviceattest\n until receipt is usually two weeks.
For foreign applicants/tenderers it is the\n experience of the Contracting Authority that the time frame for receipt of this documentation\n varies within the individual member states. As a result, The Contracting Authority\n strongly advises foreign applicants/tenderers to obtain this documentation as early\n as possible. Preferably the documentation should be ready and available already in\n connection with the prequalification.
The EU Commission has launched e-CERTIS,\n a free, on-line source of information to help companies and contracting authorities\n to deal with different forms of documentary evidence required when tendering for public\n contracts. Information regarding relevant certificates can be obtained from:
https://ec.europa.eu/tools/ecertis/#/search\n Money laundering or terrorist financing: Has the economic operator itself or any person who is a member of its administrative,\n management or supervisory body or has powers of representation, decision or control\n therein been the subject of a conviction by final judgment for money laundering or\n terrorist financing, by a conviction rendered at the most five years ago or in which\n an exclusion period set out directly in the conviction continues to be applicable?\n As defined in Article 1 of Directive 2005/60/EC of the European Parliament and of\n the Council of 26 October 2005 on the prevention of the use of the financial system\n for the purpose of money laundering and terrorist financing (OJ L 309, 25.11.2005,\n p. 15).
For Danish applicants/tenderers the documentation is entailed in the “Serviceattest”\n which can be acquired from the Danish Business Authority. The time frame from request\n of a Serviceattest until receipt is usually two weeks.
For foreign applicants/tenderers\n it is the experience of the Contracting Authority that the time frame for receipt\n of this documentation varies within the individual member states. As a result, The\n Contracting Authority strongly advises foreign applicants/tenderers to obtain this\n documentation as early as possible. Preferably the documentation should be ready and\n available already in connection with the prequalification.
The EU Commission\n has launched e-CERTIS, a free, on-line source of information to help companies and\n contracting authorities to deal with different forms of documentary evidence required\n when tendering for public contracts. Information regarding relevant certificates can\n be obtained from: https://ec.europa.eu/tools/ecertis/#/search\n Fraud: Has the economic operator itself or any person who is a member of its administrative,\n management or supervisory body or has powers of representation, decision or control\n therein been the subject of a conviction by final judgment for fraud, by a conviction\n rendered at the most five years ago or in which an exclusion period set out directly\n in the conviction continues to be applicable? Within the meaning of Article 1 of the\n Convention on the protection of the European Communities' financial interests (OJ\n C 316, 27.11.1995, p. 48).
For Danish applicants/tenderers the documentation is\n entailed in the “Serviceattest” which can be acquired from the Danish Business Authority.\n The time frame from request of a Serviceattest until receipt is usually two weeks.\n For foreign applicants/tenderers it is the experience of the Contracting Authority\n that the time frame for receipt of this documentation varies within the individual\n member states. As a result, The Contracting Authority strongly advises foreign applicants/tenderers\n to obtain this documentation as early as possible. Preferably the documentation should\n be ready and available already in connection with the prequalification. The EU Commission\n has launched e-CERTIS, a free, on-line source of information to help companies and\n contracting authorities to deal with different forms of documentary evidence required\n when tendering for public contracts. Information regarding relevant certificates can\n be obtained from: https://ec.europa.eu/tools/ecertis/#/search\n Child labour and including other forms of trafficking in human beings: Has the economic operator itself or any person who is a member of its administrative,\n management or supervisory body or has powers of representation, decision or control\n therein been the subject of a conviction by final judgment for child labour and other\n forms of trafficking in human beings, by a conviction rendered at the most five years\n ago or in which an exclusion period set out directly in the conviction continues to\n be applicable? As defined in Article 2 of Directive 2011/36/EU of the European Parliament\n and of the Council of 5 April 2011 on preventing and combating trafficking in human\n beings and protecting its victims, and replacing Council Framework Decision 2002/629/JHA\n (OJ L 101, 15.4.2011, p. 1).
For Danish applicants/tenderers the documentation\n is entailed in the “Serviceattest” which can be acquired from the Danish Business\n Authority. The time frame from request of a Serviceattest until receipt is usually\n two weeks.
For foreign applicants/tenderers it is the experience of the Contracting\n Authority that the time frame for receipt of this documentation varies within the\n individual member states. As a result, The Contracting Authority strongly advises\n foreign applicants/tenderers to obtain this documentation as early as possible. Preferably\n the documentation should be ready and available already in connection with the prequalification.\n
The EU Commission has launched e-CERTIS, a free, on-line source of information\n to help companies and contracting authorities to deal with different forms of documentary\n evidence required when tendering for public contracts. Information regarding relevant\n certificates can be obtained from: https://ec.europa.eu/tools/ecertis/#/search\n Corruption: Has the economic operator itself or any person who is a member of its administrative,\n management or supervisory body or has powers of representation, decision or control\n therein been the subject of a conviction by final judgment for corruption, by a conviction\n rendered at the most five years ago or in which an exclusion period set out directly\n in the conviction continues to be applicable? As defined in Article 3 of the Convention\n on the fight against corruption involving officials of the European Communities or\n officials of Member States of the European Union, OJ C 195, 25.6.1997, p. 1, and in\n Article 2(1) of Council Framework Decision 2003/568/JHA of 22 July 2003 on combating\n corruption in the private sector (OJ L 192, 31.7.2003, p. 54). This exclusion ground\n also includes corruption as defined in the national law of the contracting authority\n (contracting entity) or the economic operator. \"
For Danish applicants/tenderers\n the documentation is entailed in the “Serviceattest” which can be acquired from the\n Danish Business Authority. The time frame from request of a Serviceattest until receipt\n is usually two weeks. For foreign applicants/tenderers it is the experience of the\n Contracting Authority that the time frame for receipt of this documentation varies\n within the individual member states. As a result, The Contracting Authority strongly\n advises foreign applicants/tenderers to obtain this documentation as early as possible.\n Preferably the documentation should be ready and available already in connection with\n the prequalification. The EU Commission has launched e-CERTIS, a free, on-line source\n of information to help companies and contracting authorities to deal with different\n forms of documentary evidence required when tendering for public contracts. Information\n regarding relevant certificates can be obtained from: https://ec.europa.eu/tools/ecertis/#/search\n \n \n \n 5 Lot5.1 Lot: LOT-0001Title: Lot 1 - Cable crossings for new 145 kV cable systems and fiber connections across\n Guldborgsund\n Description: Two pipe sets, two power cable systems
oPipe #1 from Falster to Lolland.\n Estimated length 1,254 m
oPipe #2 from Falster to Lolland. Estimated length\n 1,207 m\n Internal identifier: 716722\n 5.1.1 PurposeMain nature of the contract: Works\n Main classification (cpv): 45120000 Test drilling and boring work\n \n \n 5.1.2 Place of performance\n Anywhere in the given country\n Additional information: Pipe #1 from Falster to Lolland. Estimated length 1254 m
Pipe #2 from Falster\n to Lolland. Estimated length 1207 m
\n \n 5.1.3 Estimated duration\n \n \n 5.1.6 General informationReserved participation: Participation is not reserved.\n The names and professional qualifications of the staff assigned to perform the contract must be given: Not required\n Procurement Project not financed with EU Funds.\n The procurement is covered by the Government Procurement Agreement (GPA): yes\n \n 5.1.9 Selection criteriaSources of selection criteria: Notice\n Criterion: Financial ratioDescription of selection criterion: The applicant must confirm the economic ability in the ESPD part IV.B with information\n from the latest annual report regarding the following economic indicators:
1.\n Equity (total equity incl. share capital, reserves, revaluation, retained earning\n etc.)
2. Equity ratio (equity/total assets). This must be stated with two decimals.
If\n the applicant relies on the capacities of other entities or the applicant is a group\n of economic operators the information for the ESPD part IV.B must also be given in\n a separate ESPD from each of these entities. It is the sole responsibility of the\n applicant to secure that the minimum requirements are reached based on consolidation\n when the applicant is relying on the capacity of other entities or when the applicant\n is a group of economic operators.
Minimum requirement:
LOT 1:
•\n Equity from the latest annual report must, at the time limit for receipt of tenders,\n be at least 28 mill. DKK/3,753 mill. EUR
• Equity ratio from the latest annual\n report must, at the time of prequalification, be at least 20 pct. If the equity ratio\n is between 15 pct. and 20 pct. the tenderer can qualify if Equity exceeds 85,75 mill.\n DKK/ 11,494 mill. EUR\n The criteria will be used to select the candidates to be invited for the second stage of the procedure\n \n Criterion: References on specified worksDescription of selection criterion: The suitability of applicants fulfilling the minimum requirements to economic and\n financial standing will be assessed based on technical and professional ability. The\n ability will be assessed based on references which can be filled in ESPD part IV.C.\n
The applicant is allowed to submit up to 3 most comparable and relevant\n references undertaken in the past 5 years as part of the application. By “com-parable”\n it is understood more than 800 m length of horizontal directional drilling involving\n 100 tons (Thrust/pull-back tension: 1000 kN) or bigger. By \"undertaken in the past\n 5 years” implies that the reference must not have been completed prior to the date\n reached when counting 5 years backwards from the submission date for prequalification.\n Ref-erences older than this will not be taken into consideration. References which\n have not yet been fully completed can be included as part of the application, however\n the applicant must describe the parts which have not yet been delivered, and this\n may affect the evaluation of the application, cf. section 2.3.
The references\n should describe horizontal directional drilling activities, and include:
A\n specific description of deliveries, including:
• Type and scope of HDD works
o\n Length and diameter of pipe installed via HDD
o Description of installed pipe/cable\n and/or casing solution
o Size of drilling rig(s) involved
• Hydro‑geological\n and environmental conditions
o Description of ground conditions encountered (e.g.\n clay, sand, moraine, rock, mixed soils)
o Sensitivity of the surrounding environment\n (e.g. Natura 2000, pro-tected areas, environmental restrictions)
• Quality, HSE\n and documentation
o Applied quality assurance and control measures
o Compliance\n with HSE requirements during drilling under marine waters
o As‑built documentation,\n drilling logs and completion reports
• Contractual role and performance
o\n Contractor’s role (main contractor / subcontractor)
o Time schedule compliance\n and handling of unforeseen ground conditions
o Reference contact details and year\n of completion
• Contact information
o Specification of buying organization,\n contact person and the asso-ciated contact information
Contract value (if\n possible)
Date of initiation and final delivery (day, month, year)
Any\n ambiguities and/or incomprehensibilities may have a negative effect on the selection\n of applicants. Please note the “description” box in ESPD part IV.C. can contain more\n text than is visible and it is possible to copy paste text into the box.
If\n the applicant is relying on the capacity of other entities or the applicant is a group\n of eco-nomic operators the maximum number of references to be submitted must still\n be respected and cannot exceed 3 when combined. If more are submitted, the Contracting\n Authority will only consider the most recent references determined by date of final\n delivery, in this case not yet finished references will not be included.
If\n the applicant relies on other entities capacity or is part of a group of economic\n operators the information concerning ESPD part IV.C must be submitted in separate\n ESPD’s for each entity.
Minimum requirement:
• At least two references\n for horizontal directional drilling of a length of more than 800 meters installing\n Ø500 PE pipes or larger within the last 5 years.
• Listing of drilling rigs of\n 100 tons (Thrust/pull-back tension: 1000 kN) and above that are relevant for the installation\n under tender
• Proven record for work in nature preservation areas like Natura\n 2000, protected areas, environmentally restricted areas or similar.
• Proven\n experience from previous projects with the use of Bentonite products, additives and\n other drilling fluid products for HDD equivalent to the products listed in Appendix\n 2E-1 and Appendix 2E-2.
\n The criteria will be used to select the candidates to be invited for the second stage of the procedure\n \n Information about the second stage of a two-stage procedure:Minimum number of candidates to be invited for the second stage of the procedure: 1\n Maximum number of candidates to be invited for the second stage of the procedure: 5\n The procedure will take place in successive stages. At each stage, some participants may be eliminated\n \n \n 5.1.10 Award criteriaCriterion:\n Description: Price
Prices must be stated in the attached Schedule of Prices and the defined\n price elements must be completed herein. Prices must be stated exclusive of VAT but\n inclu-sive of all other expenses associated with the purchase.
Prices must\n be stated in EUR.
When evaluating 'Price', the Contracting Authority will\n eval-uate the total cost - Total Tender Price, cf. Schedule of Prices.
\n Category of award weight criterion: Weight (percentage, exact)Award criterion number: 50\n \n \n Criterion:\n Description: Technical solution
Technical description
The evaluation will be based\n on the submitted technical description, including method statements specifications\n and descriptions which demonstrate the technical level for executing the works specified\n in the tender documents.
The work shall be based on a tender engineering\n ap-proach ensuring that that the proposed drilling setup is robust even if the soil\n characteristics differ from the expected.
The tenderer must include Method\n Statements and engineering reports from the Pre-FEED covering all phas-es of the Works.
Reference\n is made to Technical Requirements (doc. no. 23/03722-1)
The evaluation will\n be based on the degree of detail and the technical level of specifications and the\n level of content in the Method Statement(s).
It will be evaluated positive\n if the tenderer submits detailed descriptions that in content and clarity demonstrate\n fulfil-ment of all technical requirements stated in the tender documents. Further,\n it will be evaluated positive that the approach and chosen solutions underline the\n tenderer’s ability and use of competences to execute the works, es-pecially concerning:
•\n Assessment of technical and environmental risks and proposed mitigations
• Quality\n plan
• Method statements
• Engineering document proving that the proposed\n drilling setup is robust even if the soil characteris-tics differ from the expected\n
• Contingency plans for handling blow-outs
• Specification of specialized\n equipment and drilling rigs and drilling bits, including considerations con-cerning\n redundancy of key equipment
• Specification of materials to be used
• Specification\n of PE pipe configuration
• Specification of the PE pipes proposed.
• Specification\n of drilling mud
• Specification of seals
• State the anticipated amount of\n water for per-forming the drilling
• Preliminary drawings of drilling profile
•\n Specifications of working areas
Specification of onshore spread
\n Category of award weight criterion: Weight (percentage, exact)Award criterion number: 20\n \n \n Criterion:\n Description: Organization
As the Works is of immense importance for the Client, the tenderer\n must enclose CVs of the key personnel who will be allocated to the Works.
The\n following are considered as key personnel:
• Project manager
• Site staff\n foreman
• HSE responsible
• H&S Coordinator (AMK-B)
• Quality Manager
The\n tenderer is encouraged to highlight only the expertise and experience for each key\n personnel relevant for the position in the respective CVs (e.g. educational back-ground,\n experience within that position, experience with similar assignments etc.).
Further,\n the tenderer should submit an Organization Plan. The Organization Plan should include\n a detailed description of the project specific organizational struc-ture down to site\n staff foreman level which will be allocated to the Works during all phases of the\n Works.
The Organization Plan description should describe:
• The overall\n structure, including hierarchy and procedures for escalation.
• Lines of communication,\n internally and external-ly
• Interfaces towards the Contracting Authority.
•\n How the tenderer will secure coverage of all po-sitions at all time
The Organization\n Plan must be described in detail as well as visualized in a project specific organization\n chart.
The evaluation of key personnel will be based on the degree to which the\n experience and professional qualifications of the individual key personnel is up to\n date, relevant in respect of the performance and position of the specific assignment.\n As such a relevant educational background combined with relevant roles in recent projects\n of similar characteristics will be evaluated positively.
Further, the evaluation\n will focus on to which degree the individual key personnel will be involved in the\n fulfilment of the assignment and how the key personnel complement each other.
The\n evaluation of the Organization Plan will be based on the degree of detail and
•\n On whether the proposed plan is project specific, operational, efficient, robust and\n with clear lines of communication.
• On whether the organization is well-structured\n with coverage for all interfaces taking into consid-eration the complexity of the\n Works
• On the coverage of all positions and possibility to scall in manpower\n during execution in order to ful-fil the project time schedule
An overall\n evaluation will be made of this sub-criterion.
\n Category of award weight criterion: Weight (percentage, exact)Award criterion number: 10\n \n \n Criterion:\n Description: Time Schedule for the Works
The tenderer should include the Project Time Schedule\n in the tender. The Project Time Schedule must be project specific and include all\n activities executed by the tenderer concerning the Works.
The tenderer should\n as part of the sub-criteria include a detailed and robust time schedule for each lot\n which outlines how the works will be structured through FEED and Detailed Engineering,\n construction and pipe installation phases, and delivery of as-built documentation.\n Delays associated with inspections and verifications shall be made clear, if known.\n The time schedule should contain relevant project milestones including the milestones\n outlined in the tender documents.
Reference is made to the Time Schedule\n for the relevant LOT (LOT 1: 23/03722-34 or LOT 2: 23/03722-35).
The time\n schedule should be included both in the form of a chart (GANTT-diagram) with clarifications\n as needed, in a supporting and elaborate description.
The evaluation of the Time\n Schedule will be based on the
level of detail and robustness/timeliness for all\n phases of the Works.
The evaluation of the detailed Project Time Schedule\n pre-pared by the tenderer and included in the tender will be based on the degree of\n detail and division into sub-tasks to prove for the Employer, that the Contractor\n has the capacity to do the Works in accordance within the time frame specified in\n the Clients Time Schedule(s).
The Contracting Authority will evaluate the\n degree to which the tender demonstrates a well-planned, realistic and ro-bust time\n schedule, which allows sufficient time for potential schedule contingencies, but still\n provides evidence of a high level of security for delivery within the timeframe as\n set out in the Tender Documents.
In this context it will be evaluated positive\n that:
- the description and schedule reflect a realistic, but front-loaded schedule\n for the critical activities
- hazardous activities are not performed concurrently\n in the same location
- the division into sub-sections ensures that the ten-derer\n has the capacity to perform in accordance with the overall project time schedule.\n
the description and schedule reflect the tenderer’s ability to catch-up on delays\n and shows activities to activate
\n Category of award weight criterion: Weight (percentage, exact)Award criterion number: 10\n \n \n Criterion:\n Description: Contract terms
For the evaluation of the sub-criteria the tenderer is allowed\n to propose deviations to the elements of the contract identified as competitive elements\n in the contract terms.
The contract terms consist of:
• Contract Agreement\n for Guldborgsund, doc.no. 23/03722-15 (lot 1)
• Contract Agreement for Roskilde\n Fjord, doc.no. 23/03722-38 (lot 2)
• Appendix 1 [General Conditions based on AB18],\n doc.no. 23/03722-16 (both lots)
The deviations should be enclosed in the\n clarification list c.f. doc.no. 23/03722-6 and be included in the spreadsheet marked\n “Legal clarification”.
The submitted clarification list should be clearly marked\n “Lot 1” or “Lot 2”.
The proposed deviations should be explicit and with explanation\n as to why they are made. The tendered contract must be performed on the basis of the\n contract terms. The tenderer is allowed to propose explicit and well-explained deviations\n to the following listed competitive elements:
- In the Contract Agreements, doc.no.\n 23/03722-15 (lot 1) and doc.no. 23/03722-38 (lot 2):
• Section 5 [Contract Data]\n In terms of:
Liquidated damages and maximum liquidated damages (Clause 40, subclause\n (2)) under [Clause 40. The contractor’s liability in case of delay]
- In\n Appendix 1 [General Conditions based on AB18], doc.no. 23/03722-16 (both lots):
•\n Clause 12 [Services to be provided by the contractor]
• Clause 26 [Obstacles]
•\n Clause 31. Construction meetings
• Chapter E [Extension of time and delay]
•\n Chapter F [Handover]
• Chapter G [Defects]
• Clause 59 [The client’s right\n to terminate the contract]
Deviations to these elements will be included\n in the evaluation and it is noted that any deviations may lead to a reduction of the\n score depending on the content, clarity, and consequence of the deviation. In this\n regard it is explicitly noted that deviations which are intended to limit liability\n and shift the financial risk in favour of the tenderer will be of particular importance\n in the evaluation.
If the tenderer has no deviations to the contract terms, the\n maximum score of 10 will be awarded.
An overall evaluation for each lot will be\n made of this sub-criterion.
\n Category of award weight criterion: Weight (percentage, exact)Award criterion number: 10\n \n \n \n 5.1.11 Procurement documentsAddress of the procurement documents: https://www.comdia.com/energinet/tenderinformationshow.aspx?Id=716721\n \n 5.1.12 Terms of procurementTerms of submission:Electronic submission: Required\n Address for submission: https://www.comdia.com/energinet/tenderinformationshow.aspx?Id=716721\n Languages in which tenders or requests to participate may be submitted: English, Danish\n Electronic catalogue: Not allowed\n \n Tenderers may submit more than one tender: Not allowed\n Deadline for receipt of requests to participate: 10-07-2026 12:00 +02:00\n \n Information that can be supplemented after the submission deadline:At the discretion of the buyer, some missing tenderer-related documents may be submitted later.\n Additional information: See Tender Material\n \n Terms of contract:The execution of the contract must be performed within the framework of sheltered employment programmes: No\n Conditions relating to the performance of the contract: See contract template.\n A non-disclosure agreement is required: no\n Electronic invoicing: Required\n Electronic ordering will be used: yes\n Electronic payment will be used: yes\n Financial arrangement: See the tender materiel.
The tenderer's legal form is not required. If applications\n and tenders are submitted by a consortium, all participants in the consortium must\n be jointly and severally liable for the performance of the contract and a consortium\n member must be appointed with whom a binding agreement can be concluded on behalf\n of the consortium\n \n \n 5.1.15 Techniques\n Information about the dynamic purchasing system:No dynamic purchase system\n \n \n 5.1.16 Further information, mediation and reviewReview organisation: Danish Complaints Board for Public Procurement\n Information about review deadlines: According to the Danish Complaints Board for Public Procurement Act etc. (the Act\n can be downloaded at www.retsinformation.dk), the following deadlines for filing a\n complaint apply:
Complaints about not having been selected must be submitted to\n the Danish Complaints Board for Public Procurement within 20 calendar days, cf. Section\n 7(1) of the Act, from the day after sending a notification to the candidates concerned\n about who has been selected, when the notification is accompanied by a statement of\n reasons for the decision in accordance with Section 2(1)(1) of the Act and Section\n 171(2) of the Public Procurement Act.
In other situations, complaints about tenders,\n cf. Section 7(2) of the Act, must be submitted to the Complaints Board for Public\n Procurement within:
1) 45 calendar days after the contracting entity has published\n a notice in the Official Journal of the European Union that it has entered into a\n contract. The deadline is calculated from the day after the date on which the announcement\n has been published.
2) 20 calendar days from the day after the contracting entity\n has announced its decision, cf. Section 185(2) of the Public Procurement Act. No later\n than the same time that a complaint is submitted to the Complaints Board for Public\n Procurement, the complainant must inform the contracting entity in writing that a\n complaint is submitted to the Complaints Board for Public Procurement and whether\n the complaint has been submitted during the standstill period, cf. Section 6(4) of\n the Act. In cases where the complaint has not been submitted during the standstill\n period, the complainant must also state whether the complaint is to be given suspensive\n effect, cf. Section 12(1) of the Act.
The Complaints Board for Public Procurement's\n e-mail address is stated in Section VI.4.1).
The Complaints Board for Public Procurement's\n complaint guide can be found at: www.erhvervsstyrelsen.dk.\n Organisation providing additional information about the procurement procedure: Energinet Eltransmission A/S\n Organisation providing offline access to the procurement documents: Energinet Eltransmission A/S\n Organisation providing more information on the review procedures: Danish Competition and Consumer Authority\n Organisation receiving requests to participate: Energinet Eltransmission A/S\n Organisation processing tenders: Energinet Eltransmission A/S\n \n \n 5.1 Lot: LOT-0002Title: Lot 2 - Cable crossings for new 145 kV cable systems and fiber connections across\n Roskilde Fjord\n Description: Roskilde Fjord: One pipe set, one power cable system
oPipe #1 from Roskilde\n Fjord West – East landings. Estimated length 1,755 m
Tenders can be submitted\n for one or all partial agreements\n Internal identifier: 716723\n 5.1.1 PurposeMain nature of the contract: Works\n Main classification (cpv): 45120000 Test drilling and boring work\n \n \n 5.1.2 Place of performance\n Anywhere in the given country\n Additional information: Roskilde Fjord: Denmark - Zealand\n \n 5.1.3 Estimated duration\n \n \n 5.1.6 General informationReserved participation: Participation is not reserved.\n The names and professional qualifications of the staff assigned to perform the contract must be given: Not required\n Procurement Project not financed with EU Funds.\n The procurement is covered by the Government Procurement Agreement (GPA): yes\n \n 5.1.9 Selection criteriaSources of selection criteria: Notice\n Criterion: Financial ratioDescription of selection criterion: The applicant must confirm the economic ability in the ESPD part IV.B with information\n from the latest annual report regarding the following economic indicators:
1.\n Equity (total equity incl. share capital, reserves, revaluation, retained earning\n etc.)
2. Equity ratio (equity/total assets). This must be stated with two decimals.
If\n the applicant relies on the capacities of other entities or the applicant is a group\n of economic operators the information for the ESPD part IV.B must also be given in\n a separate ESPD from each of these entities. It is the sole responsibility of the\n applicant to secure that the minimum requirements are reached based on consolidation\n when the applicant is relying on the capacity of other entities or when the applicant\n is a group of economic operators.
Minimum requirement:
LOT 2:
•\n Equity from the latest annual report must, at the time limit for receipt of tenders,\n be at least 20 mill. DKK/2,681 mill. EUR
• Equity ratio from the latest annual\n report must, at the time of prequalification, be at least 20 pct. If the equity ratio\n is between 15 pct. and 20 pct. the tenderer can qualify if Equity exceeds 61,25 mill.\n DKK/8,210 mill. EUR\n The criteria will be used to select the candidates to be invited for the second stage of the procedure\n \n Criterion: References on specified worksDescription of selection criterion: The suitability of applicants fulfilling the minimum requirements to economic and\n financial standing will be assessed based on technical and professional ability. The\n ability will be assessed based on references which can be filled in ESPD part IV.C.\n
The applicant is allowed to submit up to 3 most comparable and relevant\n references undertaken in the past 5 years as part of the application. By “com-parable”\n it is understood more than 800 m length of horizontal directional drilling involving\n 100 tons (Thrust/pull-back tension: 1000 kN) or bigger. By \"undertaken in the past\n 5 years” implies that the reference must not have been completed prior to the date\n reached when counting 5 years backwards from the submission date for prequalification.\n Ref-erences older than this will not be taken into consideration. References which\n have not yet been fully completed can be included as part of the application, however\n the applicant must describe the parts which have not yet been delivered, and this\n may affect the evaluation of the application, cf. section 2.3.
The references\n should describe horizontal directional drilling activities, and include:
A\n specific description of deliveries, including:
• Type and scope of HDD works
o\n Length and diameter of pipe installed via HDD
o Description of installed pipe/cable\n and/or casing solution
o Size of drilling rig(s) involved
• Hydro‑geological\n and environmental conditions
o Description of ground conditions encountered (e.g.\n clay, sand, mo-raine, rock, mixed soils)
o Sensitivity of the surrounding environment\n (e.g. Natura 2000, pro-tected areas, environmental restrictions)
• Quality, HSE\n and documentation
o Applied quality assurance and control measures
o Compliance\n with HSE requirements during drilling under marine waters
o As‑built documentation,\n drilling logs and completion reports
• Contractual role and performance
o\n Contractor’s role (main contractor / subcontractor)
o Time schedule compliance\n and handling of unforeseen ground conditions
o Reference contact details and year\n of completion
• Contact information
o Specification of buying organization,\n contact person and the asso-ciated contact information
Contract value (if\n possible)
Date of initiation and final delivery (day, month, year)
Any\n ambiguities and/or incomprehensibilities may have a negative effect on the selection\n of applicants. Please note the “description” box in ESPD part IV.C. can contain more\n text than is visible and it is possible to copy paste text into the box.
If\n the applicant is relying on the capacity of other entities or the applicant is a group\n of eco-nomic operators the maximum number of references to be submitted must still\n be respected and cannot exceed 3 when combined. If more are submitted, the Contracting\n Authority will only consider the most recent references determined by date of final\n delivery, in this case not yet finished references will not be included.
If\n the applicant relies on other entities capacity or is part of a group of economic\n operators the information concerning ESPD part IV.C must be submitted in separate\n ESPD’s for each entity.
Minimum requirement:
• At least two references\n for horizontal directional drilling of a length of more than 800 meters installing\n Ø500 PE pipes or larger within the last 5 years.
• Listing of drilling rigs of\n 100 tons (Thrust/pull-back tension: 1000 kN) and above that are relevant for the installation\n under tender
• Proven record for work in nature preservation areas like Natura\n 2000, protected are-as, environmentally restricted areas or similar.
• Proven\n experience from previous projects with the use of Bentonite products, addi-tives and\n other drilling fluid products for HDD equivalent to the products listed in Ap-pendix\n 2E-1 and Appendix 2E-2.
\n The criteria will be used to select the candidates to be invited for the second stage of the procedure\n \n Information about the second stage of a two-stage procedure:Minimum number of candidates to be invited for the second stage of the procedure: 1\n Maximum number of candidates to be invited for the second stage of the procedure: 5\n The procedure will take place in successive stages. At each stage, some participants may be eliminated\n \n \n 5.1.10 Award criteriaCriterion:\n Description: Price
Prices must be stated in the attached Schedule of Prices and the defined\n price elements must be completed herein. Prices must be stated exclusive of VAT but\n inclu-sive of all other expenses associated with the purchase.
Prices must\n be stated in EUR.
When evaluating 'Price', the Contracting Authority will\n eval-uate the total cost - Total Tender Price, cf. Schedule of Prices.
\n Category of award weight criterion: Weight (percentage, exact)Award criterion number: 50\n \n \n Criterion:\n Description: Technical solution
The evaluation will be based on the submitted technical description,\n including method statements specifications and descriptions which demonstrate the\n technical level for executing the works specified in the tender docu-ments.
The\n work shall be based on a tender engineering ap-proach ensuring that that the proposed\n drilling setup is robust even if the soil characteristics differ from the expected.\n
The tenderer must include Method Statements and engineering reports from\n the Pre-FEED covering all phas-es of the Works.
Reference is made to Technical\n Requirements (doc. no. 23/03722-1)
The evaluation will be based on the degree\n of detail and the technical level of specifications and the level of content in the\n Method Statement(s).
It will be evaluated positive if the tenderer submits\n detailed descriptions that in content and clarity demonstrate fulfil-ment of all technical\n requirements stated in the tender documents. Further, it will be evaluated positive\n that the approach and chosen solutions underline the tenderer’s ability and use of\n competences to execute the works, es-pecially concerning:
• Assessment of technical\n and environmental risks and proposed mitigations
• Quality plan
• Method statements\n
• Engineering document proving that the proposed drilling setup is robust even\n if the soil characteris-tics differ from the expected
• Contingency plans for\n handling blow-outs
• Specification of specialized equipment and drilling rigs\n and drilling bits, including considerations con-cerning redundancy of key equipment
•\n Specification of materials to be used
• Specification of PE pipe configuration\n
• Specification of the PE pipes proposed.
• Specification of drilling mud
•\n Specification of seals
• State the anticipated amount of water for per-forming\n the drilling
• Preliminary drawings of drilling profile
• Specifications of\n working areas
Specification of onshore spread
\n Category of award weight criterion: Weight (percentage, exact)Award criterion number: 20\n \n \n Criterion:\n Description: Organization
As the Works is of immense importance for the Client , the tenderer\n must enclose CVs of the key personnel who will be allocated to the Works.
The\n following are considered as key personnel:
• Project manager
• Site staff\n foreman
• HSE responsible
• H&S Coordinator (AMK-B)
• Quality Manager
The\n tenderer is encouraged to highlight only the expertise and experience for each key\n personnel relevant for the position in the respective CVs (e.g. educational back-ground,\n experience within that position, experience with similar assignments etc.).
Further,\n the tenderer should submit an Organization Plan. The Organization Plan should include\n a detailed description of the project specific organizational structure down to site\n staff foreman level which will be allocated to the Works during all phases of the\n Works.
The Organization Plan description should describe:
• The overall\n structure, including hierarchy and procedures for escalation.
• Lines of communication,\n internally and external-ly
• Interfaces towards the Contracting Authority.
•\n How the tenderer will secure coverage of all po-sitions at all time
The Organization\n Plan must be described in detail as well as visualized in a project specific organization\n chart.
The evaluation of key personnel will be based on the degree to which the\n experience and professional qualifications of the individual key personnel is up to\n date, relevant in respect of the performance and position of the specific assignment.\n As such a relevant educational background combined with relevant roles in recent projects\n of similar char-acteristics will be evaluated positively.
Further, the evaluation\n will focus on to which degree the individual key personnel will be involved in the\n fulfilment of the assignment and how the key personnel complement each other.
The\n evaluation of the Organization Plan will be based on the degree of detail and
•\n On whether the proposed plan is project specific, operational, efficient, robust and\n with clear lines of communication.
• On whether the organization is well-structured\n with coverage for all interfaces taking into consideration the complexity of the Works
•\n On the coverage of all positions and possibility to scall in manpower during execution\n in order to fulfil the project time schedule
An overall evaluation will\n be made of this sub-criterion
\n Category of award weight criterion: Weight (percentage, exact)Award criterion number: 10\n \n \n Criterion:\n Description: Time Schedule for the Works
The tenderer should include the Project Time Schedule\n in the tender. The Project Time Schedule must be project specific and include all\n activities executed by the tenderer concerning the Works.
The tenderer should\n as part of the sub-criteria include a detailed and robust time schedule for each lot\n which outlines how the works will be structured through FEED and Detailed Engineering,\n construction and pipe installation phases, and delivery of as-built documentation.\n Delays associated with inspections and verifications shall be made clear, if known.\n The time schedule should contain relevant project milestones including the milestones\n outlined in the tender documents.
Reference is made to the Time Schedule\n for the relevant LOT (LOT 1: 23/03722-34 or LOT 2: 23/03722-35).
The time\n schedule should be included both in the form of a chart (GANTT-diagram) with clarifications\n as needed, in a supporting and elaborate description.
The evaluation of\n the Time Schedule will be based on the
level of detail and robustness/timeliness\n for all phases of the Works.
The evaluation of the detailed Project Time\n Schedule prepared by the tenderer and included in the tender will be based on the\n degree of detail and division into sub-tasks to prove for the Employer, that the Contractor\n has the capacity to do the Works in accordance within the time frame specified in\n the Clients Time Schedule(s).
The Contracting Authority will evaluate the\n degree to which the tender demonstrates a well-planned, realistic and robust time\n schedule, which allows sufficient time for potential schedule contingencies, but still\n provides evidence of a high level of security for delivery within the timeframe as\n set out in the Tender Documents.
In this context it will be evaluated positive\n that:
- the description and schedule reflect a realistic, but front-loaded schedule\n for the critical activities
- hazardous activities are not performed concurrently\n in the same location
- the division into sub-sections ensures that the tenderer\n has the capacity to perform in accordance with the overall project time schedule.\n
the description and schedule reflect the tenderer’s ability to catch-up on delays\n and shows activities to activate
\n Category of award weight criterion: Weight (percentage, exact)Award criterion number: 10\n \n \n Criterion:\n Description: Contract terms
For the evaluation of the sub-criteria the tenderer is allowed\n to propose deviations to the elements of the contract identified as competitive elements\n in the contract terms.
The contract terms consist of:
• Contract Agreement\n for Guldborgsund, doc.no. 23/03722-15 (lot 1)
• Contract Agreement for Roskilde\n Fjord, doc.no. 23/03722-38 (lot 2)
• Appendix 1 [General Conditions based on AB18],\n doc.no. 23/03722-16 (both lots)
The deviations should be enclosed in the\n clarification list c.f. doc.no. 23/03722-6 and be included in the spreadsheet marked\n “Legal clarification”.
The submitted clarification list should be clearly marked\n “Lot 1” or “Lot 2”.
The proposed deviations should be explicit and with explanation\n as to why they are made. The tendered contract must be performed on the basis of the\n contract terms. The tenderer is allowed to propose explicit and well-explained deviations\n to the following listed competitive elements:
- In the Contract Agreements, doc.no.\n 23/03722-15 (lot 1) and doc.no. 23/03722-38 (lot 2):
• Section 5 [Contract Data]\n In terms of:
Liquidated damages and maximum liquidated damages (Clause 40, subclause\n (2)) under [Clause 40. The contractor’s liability in case of delay]
- In\n Appendix 1 [General Conditions based on AB18], doc.no. 23/03722-16 (both lots):
•\n Clause 12 [Services to be provided by the contractor]
• Clause 26 [Obstacles]
•\n Clause 31. Construction meetings
• Chapter E [Extension of time and delay]
•\n Chapter F [Handover]
• Chapter G [Defects]
• Clause 59 [The client’s right\n to terminate the contract]
Deviations to these elements will be included\n in the evaluation and it is noted that any deviations may lead to a reduction of the\n score depending on the content, clarity, and consequence of the deviation. In this\n regard it is explicitly noted that deviations which are intended to limit liability\n and shift the financial risk in favour of the tenderer will be of particular importance\n in the evaluation.
If the tenderer has no deviations to the contract terms, the\n maximum score of 10 will be awarded.
An overall evaluation for each lot will be\n made of this sub-criterion.
\n Category of award weight criterion: Weight (percentage, exact)Award criterion number: 10\n \n \n \n 5.1.11 Procurement documentsAddress of the procurement documents: https://www.comdia.com/energinet/tenderinformationshow.aspx?Id=716721\n \n 5.1.12 Terms of procurementTerms of submission:Electronic submission: Required\n Address for submission: https://www.comdia.com/energinet/tenderinformationshow.aspx?Id=716721\n Languages in which tenders or requests to participate may be submitted: English, Danish\n Electronic catalogue: Not allowed\n Deadline for receipt of requests to participate: 10-07-2026 12:00 +02:00\n \n Information that can be supplemented after the submission deadline:At the discretion of the buyer, some missing tenderer-related documents may be submitted later.\n Additional information: See Tender Material\n \n Terms of contract:The execution of the contract must be performed within the framework of sheltered employment programmes: No\n Conditions relating to the performance of the contract: See contract template.\n A non-disclosure agreement is required: no\n Electronic invoicing: Required\n Electronic ordering will be used: yes\n Electronic payment will be used: yes\n Financial arrangement: See the tender materiel.
The tenderer's legal form is not required. If applications\n and tenders are submitted by a consortium, all participants in the consortium must\n be jointly and severally liable for the performance of the con-tract and a consortium\n member must be appointed with whom a binding agreement can be concluded on behalf\n of the consortium\n \n \n 5.1.15 Techniques\n Information about the dynamic purchasing system:No dynamic purchase system\n \n \n 5.1.16 Further information, mediation and reviewReview organisation: Danish Complaints Board for Public Procurement\n Information about review deadlines: According to the Danish Complaints Board for Public Procurement Act etc. (the Act\n can be downloaded at www.retsinformation.dk), the following deadlines for filing a\n complaint apply:
Complaints about not having been selected must be submitted to\n the Danish Complaints Board for Public Procurement within 20 calendar days, cf. Section\n 7(1) of the Act, from the day after sending a notification to the candidates concerned\n about who has been selected, when the notification is accompanied by a statement of\n reasons for the decision in accordance with Section 2(1)(1) of the Act and Section\n 171(2) of the Public Procurement Act.
In other situations, complaints about tenders,\n cf. Section 7(2) of the Act, must be submitted to the Complaints Board for Public\n Procurement within:
1) 45 calendar days after the contracting entity has published\n a notice in the Official Journal of the European Union that it has entered into a\n contract. The deadline is calculated from the day after the date on which the announcement\n has been published.
2) 20 calendar days from the day after the contracting entity\n has announced its decision, cf. Section 185(2) of the Public Procurement Act. No later\n than the same time that a complaint is submitted to the Complaints Board for Public\n Procurement, the complainant must inform the contracting entity in writing that a\n complaint is submitted to the Complaints Board for Public Procurement and whether\n the complaint has been submitted during the standstill period, cf. Section 6(4) of\n the Act. In cases where the complaint has not been submitted during the standstill\n period, the complainant must also state whether the complaint is to be given suspensive\n effect, cf. Section 12(1) of the Act.
The Complaints Board for Public Procurement's\n e-mail address is stated in Section VI.4.1).
The Complaints Board for Public Procurement's\n complaint guide can be found at: www.erhvervsstyrelsen.dk.\n Organisation providing additional information about the procurement procedure: Energinet Eltransmission A/S\n Organisation providing offline access to the procurement documents: Energinet Eltransmission A/S\n Organisation providing more information on the review procedures: Danish Competition and Consumer Authority\n Organisation receiving requests to participate: Energinet Eltransmission A/S\n Organisation processing tenders: Energinet Eltransmission A/S\n \n \n \n 8 Organisations8.1 ORG-0001Official name: Energinet Eltransmission A/S\n Registration number: 39314878\n Postal address: Tonne Kjærsvej 65 \n \n \n Country subdivision (NUTS): Sydjylland (DK032)\n \n Contact point: Procurement - A\n Email: procurement@energinet.dk\n \n Internet address: https://energinet.dk/\n Roles of this organisation:\n Organisation providing additional information about the procurement procedure\n Organisation providing offline access to the procurement documents\n Organisation receiving requests to participate\n Organisation processing tenders\n \n \n 8.1 ORG-1000Official name: Comdia ApS\n Registration number: 33501404\n Postal address: Lindvedvej 71 \n \n \n Country subdivision (NUTS): Fyn (DK031)\n \n Email: support@comdia.com\n \n Internet address: https://www.comdia.com/\n Roles of this organisation:\n \n \n 8.1 ORG-1001Official name: Danish Complaints Board for Public Procurement\n Registration number: 37795526\n Postal address: Danish Appeals Boards Authority, Toldboden 2 \n \n \n Country subdivision (NUTS): Vestjylland (DK041)\n \n Email: klfu@naevneneshus.dk\n \n Internet address: http://www.klfu.dk\n Roles of this organisation:\n \n \n 8.1 ORG-1002Official name: Danish Competition and Consumer Authority\n Registration number: 10294819\n Postal address: Carl Jacobsens Vej 35 \n \n \n Country subdivision (NUTS): Københavns omegn (DK012)\n \n \n \n Internet address: https://www.kfst.dk/\n Roles of this organisation:Organisation providing more information on the review procedures\n \n \n \n 10 ChangeVersion of the previous notice to be changed: 335420-2026\n Main reason for change: Buyer correction\n Description: Energinet has decided to extend the period of validity for references from 5 to 10\n years. The change has been made to ensure a sufficiently broad and competitive pool\n of applicants, without compromising the requirements regarding the applicants’ relevant\n experience. The validity of references has been changed in the tender conditions as\n well as in the ESPD. The extension of the period of validity for references from 5\n to 10 years applies for both LOTS (LOT 1 and LOT 2)
Furthermore, Energinet\n has decided to accept references concerning the installation of steel pipes as equivalent\n to references concerning horizontal directional drilling involving the installation\n of PE pipes. Section 2.2.2 concerning the minimum requirements has been amended accordingly.
Due\n to the above changes regarding the validity of references, deadline for submission\n of prequalification has been extended. The new date for submission of prequalification\n is 10 July 2026, at 12:00 (noon)Danish local time.
\n \n Notice informationNotice identifier/version: 16e54f80-aedc-4ec2-9421-bf3e8928ba28 - 01\n \n Notice type: Contract or concession notice – standard regime\n Notice dispatch date: 11-06-2026 14:07 +02:00\n Languages in which this notice is officially available: English \n Notice publication number: 00405713-2026\n OJ S issue number: 112/2026\n Publication date: 12-06-2026\n \n \n","opsummeringDA":{"card":{"titel":"Installation of pipes with horizontal directional drilling (HDD) under Guldborgsund and Roskilde Fjord - 23/03722","ordregiver":"Energinet Eltransmission A/S","ordregiverId":"39314878","ordregiverIdDatavasket":"39314878","publiceringsdato":"2026-06-12+02:00","cpvKode":"45120000","cpvTitel":"Prøve- og udboring","formulartype":"Konkurrencevilkår","formulartypeKode":"competition","tidsfrister":["2026-07-10T12:00:00+02:00","2026-07-10T12:00:00+02:00"],"alleOrdregivere":["Energinet Eltransmission A/S"],"anslaaetVaerdi":"147000000","anslaaetVaerdiValuta":"DKK","beskrivelse":"The Contracting Authority wants to purchase horizontal directional drilling activities including installation of PE-pipes for establishing two sets of cable crossings for new 145 kV cable sys-tems and fiber connections across Guldborgsund (two pipe sets, two cable systems, LOT 1) and Roskilde Fjord (one pipe set, one cable system, LOT 2). \n\nThe underground power cables will be installed by another Contractor by means of Watucab by utilizing the smaller pipes inside a bigger pipe. The Fibre Optical Cables (FOC) will be installed in dedicated pipes for this purpose. This tender concerns all pipes involved – both the smaller pipes and the bigger pipe on the outside. \n\nFor further details regarding the purchase, reference is made to the tender documents. \n\nThe value of the contracts is expected to amount to total 147 Mio. DKK \n\nThe tender is divided into the following lots: \n\nLot 1: \n\nCable crossings for new 145 kV cable systems and fiber connections across Guldborgsund. Two pipe sets, two power cable systems \n\noPipe #1 from Falster to Lolland. Estimated length 1,254 m \n\noPipe #2 from Falster to Lolland. Estimated length 1,207 m \n\nLot 2: Cable crossings for new 145 kV cable systems and fiber connections across\n\nRoskilde Fjord: One pipe set, one power cable system \n\noPipe #1 from Roskilde Fjord West – East landings. Estimated length 1,755 m \n\nTenders can be submitted for one or all partial agreements","bkSubTypeKode":"17","bkSubType":"Udbudsbekendtgørelse – sektordirektivet, standardordningen","erAendring":true},"indholdsType":"HENTET_FRA_TED","sekundaereOrdregivere":[],"udforelsesstedNutsCode":[],"udforelsesstedSubLand":[],"udforelsesstedLand":["Danmark"],"udforelsesstedBy":[],"tilbudsfrister":[],"intressentfrister":[],"deltagelsefrister":["2026-07-10T12:00:00+02:00","2026-07-10T12:00:00+02:00"],"svarfrister":[],"antalParts":0,"antalLots":2,"udbudsDokumenter":["https://www.comdia.com/energinet/tenderinformationshow.aspx?Id=716721"]},"opsummeringEN":{"card":{"titel":"Installation of pipes with horizontal directional drilling (HDD) under Guldborgsund and Roskilde Fjord - 23/03722","ordregiver":"Energinet Eltransmission A/S","ordregiverId":"39314878","ordregiverIdDatavasket":"39314878","publiceringsdato":"2026-06-12+02:00","cpvKode":"45120000","cpvTitel":"Test drilling and boring work","formulartype":"Competition","formulartypeKode":"competition","tidsfrister":["2026-07-10T12:00:00+02:00","2026-07-10T12:00:00+02:00"],"alleOrdregivere":["Energinet Eltransmission A/S"],"anslaaetVaerdi":"147000000","anslaaetVaerdiValuta":"DKK","beskrivelse":"The Contracting Authority wants to purchase horizontal directional drilling activities including installation of PE-pipes for establishing two sets of cable crossings for new 145 kV cable sys-tems and fiber connections across Guldborgsund (two pipe sets, two cable systems, LOT 1) and Roskilde Fjord (one pipe set, one cable system, LOT 2). \n\nThe underground power cables will be installed by another Contractor by means of Watucab by utilizing the smaller pipes inside a bigger pipe. The Fibre Optical Cables (FOC) will be installed in dedicated pipes for this purpose. This tender concerns all pipes involved – both the smaller pipes and the bigger pipe on the outside. \n\nFor further details regarding the purchase, reference is made to the tender documents. \n\nThe value of the contracts is expected to amount to total 147 Mio. DKK \n\nThe tender is divided into the following lots: \n\nLot 1: \n\nCable crossings for new 145 kV cable systems and fiber connections across Guldborgsund. Two pipe sets, two power cable systems \n\noPipe #1 from Falster to Lolland. Estimated length 1,254 m \n\noPipe #2 from Falster to Lolland. Estimated length 1,207 m \n\nLot 2: Cable crossings for new 145 kV cable systems and fiber connections across\n\nRoskilde Fjord: One pipe set, one power cable system \n\noPipe #1 from Roskilde Fjord West – East landings. Estimated length 1,755 m \n\nTenders can be submitted for one or all partial agreements","bkSubTypeKode":"17","bkSubType":"Contract notice – sectoral directive, standard regime","erAendring":true},"indholdsType":"HENTET_FRA_TED","sekundaereOrdregivere":[],"udforelsesstedNutsCode":[],"udforelsesstedSubLand":[],"udforelsesstedLand":["Denmark"],"udforelsesstedBy":[],"tilbudsfrister":[],"intressentfrister":[],"deltagelsefrister":["2026-07-10T12:00:00+02:00","2026-07-10T12:00:00+02:00"],"svarfrister":[],"antalParts":0,"antalLots":2,"udbudsDokumenter":["https://www.comdia.com/energinet/tenderinformationshow.aspx?Id=716721"]}}